UNITED STATES
SECURITIES AND EXCHANGE COMMISSION
Washington, D.C. 20549
Form 10-Q
| |
☒ | QUARTERLY REPORT PURSUANT TO SECTION 13 OR 15(d) OF THE SECURITIES EXCHANGE ACT OF 1934 |
| |
☐ | TRANSITION REPORT PURSUANT TO SECTION 13 OR 15(d) OF THE SECURITIES EXCHANGE ACT OF 1934 |
For the quarterly period ended July 31, 2023
Commission File No. 001-31552
Smith & Wesson Brands, Inc.
(Exact name of registrant as specified in its charter)
| | |
Nevada |
| 87-0543688 |
(State or other jurisdiction of incorporation or organization) |
| (I.R.S. Employer Identification No.) |
| | |
2100 Roosevelt Avenue Springfield, Massachusetts |
| 01104 |
(Address of principal executive offices) |
| (Zip Code) |
(800) 331-0852
(Registrant’s telephone number, including area code)
Securities registered pursuant to Section 12(b) of the Act:
| | |
Title of each Class | Trading Symbol | Name of exchange on which registered |
Common Stock, par value $0.001 per share | SWBI | Nasdaq Global Select Market |
Indicate by check mark whether the registrant: (1) has filed all reports required to be filed by Section 13 or 15(d) of the Securities Exchange Act of 1934 during the preceding 12 months (or for such shorter period that the registrant was required to file such reports), and (2) has been subject to such filing requirements for the past 90 days. Yes ☒ No ☐
Indicate by check mark whether the registrant has submitted electronically every Interactive Data File required to be submitted pursuant to Rule 405 of Regulation S-T (§ 232.405 of this chapter) during the preceding 12 months (or for such shorter period that the registrant was required to submit such files). Yes ☒ No ☐
Indicate by check mark whether the registrant is a large accelerated filer, an accelerated filer, a non-accelerated filer, a smaller reporting company, or an emerging growth company. See the definitions of “large accelerated filer,” “accelerated filer,” “smaller reporting company,” and “emerging growth company” in Rule 12b-2 of the Exchange Act.
| | | | | | | |
Large accelerated filer |
| ☐ |
| Accelerated filer |
| ☒ |
| | | |
Non-accelerated filer |
| ☐ |
| Smaller reporting company |
| ☐ |
| | | | |
Emerging growth company |
| ☐ | |
| | |
If an emerging growth company, indicate by check mark if the registrant has elected not to use the extended transition period for complying with any new or revised financial accounting standards provided pursuant to Section 13(a) of the Exchange Act. ☐
Indicate by check mark whether the registrant is a shell company (as defined in Rule 12b-2 of the Exchange Act). Yes ☐ No ☒
The registrant had 46,148,451 shares of common stock, par value $0.001, outstanding as of September 5, 2023.
SMITH & WESSON BRANDS, INC.
Quarterly Report on Form 10-Q
For the Three Months Ended July 31, 2023 and 2022
TABLE OF CONTENTS
Smith & Wesson®, S&W®, M&P®, M&P Shield®, Performance Center®, Airlite®, Airweight®, American Guardians®, America’s Master Gunmaker®, Armornite®, Arrow®, Aurora®, Aurora-II®, Blast Jacket®, Bodyguard®, Carry Comp®, Chiefs Special®, Club 1852®, Compass®, Competitor®, Contender®, CSX®, Dagger®, Encore®, E-Series®, EZ®, Flextech®, G-Core®, Gemtech®, Gemtech Suppressors®, Gemtech World-Class Silencers®, GM®, GMT-Halo®, Governor®, Integra®, Lady Smith®, Lever Lock®, Lunar®, M&P FPC®, M2.0®, Mag Express®, Magnum®, Maxi-Hunter®, Mist-22®, Mountain Gun®, Number 13®, PC®, Power Rod®, Protected by Smith & Wesson®, Put A Legend On Your Line®, QLA®, Quick Load Accurizor®, Quickmount®, Shield®, Smith & Wesson Collectors Association®, Smith & Wesson Performance Center®, Smith & Wesson Precision Components®, Speed Breech®, Speed Breach XT®, SW Equalizer®, SW22 Victory®, Swing Hammer®, T/C®, T/CR22®, T17®, The S&W Bench®, The Sigma Series®, Thompson/Center®, Trek®, Triumph®, U-View®, Viper®, Volunteer®, and Weather Shield® are some of the registered U.S. trademarks of our company or one of our subsidiaries. This report also may contain trademarks and trade names of other companies.
Statement Regarding Forward-Looking Information
The statements contained in this Quarterly Report on Form 10-Q that are not purely historical are forward-looking statements within the meaning of Section 27A of the Securities Act of 1933, as amended, and Section 21E of the Securities Exchange Act of 1934, as amended. All statements other than statements of historical facts contained or incorporated herein by reference in this Quarterly Report on Form 10-Q, including statements regarding our future operating results, future financial position, business strategy, objectives, goals, plans, prospects, markets, and plans and objectives for future operations, are forward-looking statements. In some cases, you can identify forward-looking statements by terms such as “anticipates,” “believes,” “estimates,” “expects,” “intends,” “targets,” “contemplates,” “projects,” “predicts,” “may,” “might,” “plan,” “will,” “would,” “should,” “could,” “may,” “can,” “potential,” “continue,” “objective,” or the negative of those terms, or similar expressions intended to identify forward-looking statements. However, not all forward-looking statements contain these identifying words. Specific forward-looking statements in this Quarterly Report on Form 10-Q include statements regarding plans to move our headquarters and certain of our manufacturing operations to a new facility being constructed in Maryville, Tennessee; lease payments for future periods; estimated amortization expense of intangible assets for future periods; our intention to terminate the Sublease (as defined herein) on or around the effective date of the Assignment and Assumption Agreement (as defined herein); our intention to occupy our Connecticut facility through the lease term; the outcome of the lawsuits to which we are subject and their effect on us; our belief that the claims asserted by Gemini (as defined herein) and plaintiffs in a putative class action against us have no merit and that we intend to aggressively defend these actions; our belief with respect to certain matters described in the Commitments and Contingencies – Litigation section, that the allegations are unfounded and that any incident and any results from them or any injuries were due to negligence or misuse of the firearm by the claimant or a third party; our belief that our accruals for product liability cases and claims are a reasonable quantitative measure of the cost to us of product liability cases and claims; our belief that we have provided adequate accruals for defense costs; our expectation to incur capital expenditures in connection with the construction and equipping of the new facility in Maryville, Tennessee in an aggregate amount of approximately $160.0 million to $170.0 million through the end of fiscal 2024; our intention, with respect to assets associated with our assembly operations in Massachusetts and distribution operations in Missouri, to either move those assets to the Maryville facility at the appropriate time or sell or sublease those assets that will not be moved; our expectation that subsequent to the Relocation, our Massachusetts facility will continue to remain an important part of our manufacturing activities with significant portions of the operations being unaffected by the Relocation; our intention to relocate a portion of the plastic injection molding operations to Tennessee, which is expected to begin in our second quarter of 2023, and evaluate selling the remaining molding operations utilized in our Connecticut operations to a third party; our inventory levels, both internally and in the distribution channel, in excess of demand may negatively impact future operating results; our expectation that our inventory levels will decline by the end of the fiscal year due to the completion of a significant portion of the operational transition to the new Maryville facility combined with alignment of production capacity to channel inventory and consumer demand; our expectation for capital expenditures in fiscal 2024, including spending related to the Relocation; factors affecting our future capital requirements; availability of equity or debt financing on acceptable terms, if at all; the record date and payment date for our dividend; and our belief that our existing capital resources and credit facilities will be adequate to fund our operations, including our finance leases and other commitments, for the next 12 months. All forward-looking statements included herein are based on information available to us as of the date hereof and speak only as of such date. Except as required by law, we undertake no obligation to update any forward-looking statements to reflect events or circumstances after the date of such statements. The forward-looking statements contained in or incorporated by reference into this Quarterly Report on Form 10-Q reflect our views as of the date hereof about future events and are subject to risks, uncertainties, assumptions, and changes in circumstances that may cause our actual results, performance, or achievements to differ significantly from those expressed or implied in any forward-looking statement. Although we believe that the expectations reflected in the forward-looking statements are reasonable, we cannot guarantee future events, results, performance, or achievements. A number of factors could cause actual results to differ materially from those indicated by the forward-looking statements. Such factors include, among others, economic, political, social, legislative, regulatory, inflationary, and health factors; the potential for increased regulation of firearms and firearm-related products; actions of social activists that could have an adverse effect on our business; the impact of lawsuits; the demand for our products; the state of the U.S. economy in general and the firearm industry in particular; general economic conditions and consumer spending patterns; our competitive environment; the supply, availability, and costs of raw materials and components; speculation surrounding fears of terrorism and crime; our anticipated growth and growth opportunities; our ability to effectively manage and execute the Relocation; our ability to increase demand for our products in various markets, including consumer, law enforcement, and military channels, domestically and internationally; our penetration rates in new and existing markets; our strategies; our ability to maintain and enhance brand recognition and reputation; our ability to introduce new products; the success of new products; our ability to expand our markets; the potential for cancellation of orders from our backlog; and other factors detailed from time to time in our reports filed with the Securities and Exchange Commission, or the SEC, including our Annual Report on Form 10-K for the fiscal year ended April 30, 2023, or the Fiscal 2023 Form 10-K.
PART I — FINANCIAL INFORMATION
Item 1. Financial Statements
SMITH & WESSON BRANDS, INC. AND SUBSIDIARIES
CONDENSED CONSOLIDATED BALANCE SHEETS
(Unaudited)
| | | | | | | | |
| | As of: | |
| | July 31, 2023 | | | April 30, 2023 | |
| | (In thousands, except par value and share data) | |
ASSETS | |
Current assets: | | | | | | |
Cash and cash equivalents | | $ | 55,479 | | | $ | 53,556 | |
Accounts receivable, net of allowances for credit losses of $17 on July 31, 2023 and $23 on April 30, 2023 | | | 28,164 | | | | 55,153 | |
Inventories | | | 170,754 | | | | 177,118 | |
Prepaid expenses and other current assets | | | 8,741 | | | | 4,917 | |
Income tax receivable | | | 1,015 | | | | 1,176 | |
Total current assets | | | 264,153 | | | | 291,920 | |
Property, plant, and equipment, net | | | 234,595 | | | | 210,330 | |
Intangibles, net | | | 3,534 | | | | 3,588 | |
Goodwill | | | 19,024 | | | | 19,024 | |
Deferred income taxes | | | 8,085 | | | | 8,085 | |
Other assets | | | 8,271 | | | | 8,347 | |
Total assets | | $ | 537,662 | | | $ | 541,294 | |
LIABILITIES AND STOCKHOLDERS’ EQUITY | |
Current liabilities: | | | | | | |
Accounts payable | | $ | 36,335 | | | $ | 36,795 | |
Accrued expenses and deferred revenue | | | 16,041 | | | | 20,149 | |
Accrued payroll and incentives | | | 20,117 | | | | 18,565 | |
Accrued income taxes | | | 2,585 | | | | 1,831 | |
Accrued profit sharing | | | 8,971 | | | | 8,203 | |
Accrued warranty | | | 1,753 | | | | 1,670 | |
Total current liabilities | | | 85,802 | | | | 87,213 | |
Notes and loans payable (Note 4) | | | 24,813 | | | | 24,790 | |
Finance lease payable, net of current portion | | | 36,591 | | | | 36,961 | |
Other non-current liabilities | | | 7,741 | | | | 7,707 | |
Total liabilities | | | 154,947 | | | | 156,671 | |
Commitments and contingencies (Note 9) | | | | | | |
Stockholders’ equity: | | | | | | |
Preferred stock, $0.001 par value, 20,000,000 shares authorized, no shares issued or outstanding | | | — | | | | — | |
Common stock, $0.001 par value, 100,000,000 shares authorized, 75,183,851 issued and 46,143,481 shares outstanding on July 31, 2023 and 75,029,300 shares issued and 45,988,930 shares outstanding on April 30, 2023 | | | 75 | | | | 75 | |
Additional paid-in capital | | | 284,176 | | | | 283,666 | |
Retained earnings | | | 520,766 | | | | 523,184 | |
Accumulated other comprehensive income | | | 73 | | | | 73 | |
Treasury stock, at cost (29,040,370 shares on July 31, 2023 and April 30, 2023) | | | (422,375 | ) | | | (422,375 | ) |
Total stockholders’ equity | | | 382,715 | | | | 384,623 | |
Total liabilities and stockholders' equity | | $ | 537,662 | | | $ | 541,294 | |
The accompanying notes are an integral part of these condensed consolidated financial statements.
4
SMITH & WESSON BRANDS, INC. AND SUBSIDIARIES
CONDENSED CONSOLIDATED STATEMENTS OF INCOME
(Unaudited)
| | | | | | | |
| For the Three Months Ended July 31, | |
| 2023 | | | 2022 | |
| (In thousands, except per share data) | |
Net sales | $ | 114,243 | | | $ | 84,394 | |
Cost of sales | | 83,842 | | | | 52,923 | |
Gross profit | | 30,401 | | | | 31,471 | |
Operating expenses: | | | | | |
Research and development | | 1,799 | | | | 1,673 | |
Selling, marketing, and distribution | | 10,040 | | | | 8,027 | |
General and administrative | | 14,213 | | | | 17,854 | |
Total operating expenses | | 26,052 | | | | 27,554 | |
Operating income | | 4,349 | | | | 3,917 | |
Other income/(expense), net: | | | | | |
Other income/(expense), net | | 47 | | | | 673 | |
Interest income/(expense), net | | 153 | | | | (433 | ) |
Total other income/(expense), net | | 200 | | | | 240 | |
Income from operations before income taxes | | 4,549 | | | | 4,157 | |
Income tax expense | | 1,431 | | | | 845 | |
Net income | $ | 3,118 | | | $ | 3,312 | |
Net income per share: | | | | | |
Basic - net income | $ | 0.07 | | | $ | 0.07 | |
Diluted - net income | $ | 0.07 | | | $ | 0.07 | |
Weighted average number of common shares outstanding: | | | | | |
Basic | | 46,103 | | | | 45,739 | |
Diluted | | 46,551 | | | | 46,102 | |
The accompanying notes are an integral part of these condensed consolidated financial statements.
5
SMITH & WESSON BRANDS, INC. AND SUBSIDIARIES
CONDENSED CONSOLIDATED STATEMENTS OF CHANGES IN STOCKHOLDERS’ EQUITY
(Unaudited)
| | | | | | | | | | | | | | | | | | | | | | | | | | | | | | | | |
| | | |
| | |
| | |
| | |
| Accumulated | |
| | |
| | | | | |
| | Common | |
| Additional | |
| | | | Other | |
| | | | | | | Total | |
| | Stock | |
| Paid-In | |
| Retained | | | Comprehensive | | | Treasury Stock | | | Stockholders’ | |
(In thousands) | | Shares | |
| Amount | |
| Capital | |
| Earnings | |
| Income | |
| Shares | |
| Amount | | | Equity | |
Balance at April 30, 2022 | | | 74,641 | |
| $ | 75 | |
| $ | 278,101 | |
| $ | 504,640 | |
| $ | 73 | |
| | 29,040 | |
| $ | (422,375 | ) |
| $ | 360,514 | |
Stock-based compensation | | | — | | | | — | | | | 1,177 | | | | — | | | | — | | | | — | | | | — | | | | 1,177 | |
Issuance of common stock under restricted stock unit awards, net of shares surrendered | | | 170 | | | | — | | | | (981 | ) | | | — | | | | — | | | | — | | | | — | | | | (981 | ) |
Dividends issued | | — | | | — | | | — | | | | (4,576 | ) | | — | | | — | | | — | | | | (4,576 | ) |
Net income | | | — | | | | — | | | — | | | | 3,312 | | | | — | | | | — | | | | — | | | | 3,312 | |
Balance at July 31, 2022 | | | 74,811 | |
| $ | 75 | |
| $ | 278,297 | |
| $ | 503,376 | |
| $ | 73 | |
| | 29,040 | |
| $ | (422,375 | ) |
| $ | 359,446 | |
| | | | | | | | | | | | | | | | | | | | | | | | |
Balance at April 30, 2023 | | | 75,029 | |
| $ | 75 | |
| $ | 283,666 | |
| $ | 523,184 | |
| $ | 73 | |
| | 29,040 | |
| $ | (422,375 | ) |
| $ | 384,623 | |
Stock-based compensation | | | — | | | | — | | | | 1,276 | | | | — | | | | — | | | | — | | | | — | | | | 1,276 | |
Issuance of common stock under restricted stock unit awards, net of shares surrendered | | | 155 | | | | — | | | | (766 | ) | | | — | | | | — | | | | — | | | | — | | | | (766 | ) |
Dividends issued | | — | | | — | | | — | | | | (5,536 | ) | | — | | | — | | | — | | | | (5,536 | ) |
Net income | | | — | | | | — | | | — | | | | 3,118 | | | | — | | | | — | | | | — | | | | 3,118 | |
Balance at July 31, 2023 | | | 75,184 | |
| $ | 75 | |
| $ | 284,176 | |
| $ | 520,766 | |
| $ | 73 | |
| | 29,040 | |
| $ | (422,375 | ) |
| $ | 382,715 | |
The accompanying notes are an integral part of these condensed consolidated financial statements.
6
SMITH & WESSON BRANDS, INC. AND SUBSIDIARIES
CONDENSED CONSOLIDATED STATEMENTS OF CASH FLOWS
(Unaudited)
| | | | | | | | |
| | For the Three Months Ended July 31, | |
| | 2023 | | | 2022 | |
| | (In thousands) | |
Cash flows from operating activities: | | | | | | |
Net income | | $ | 3,118 | | | $ | 3,312 | |
Adjustments to reconcile net income to net cash provided by operating activities: | | | | | | |
Depreciation and amortization | | | 9,253 | | | | 7,549 | |
Loss/(gain) on sale/disposition of assets | | | 3 | | | | (46 | ) |
Provision for recoveries on notes and accounts receivable | | | (6 | ) | | | (21 | ) |
Stock-based compensation expense | | | 1,276 | | | | 1,177 | |
Changes in operating assets and liabilities: | | | | | | |
Accounts receivable | | | 26,995 | | | | 38,935 | |
Inventories | | | 6,363 | | | | (45,841 | ) |
Prepaid expenses and other current assets | | | (3,825 | ) | | | (3,324 | ) |
Income taxes | | | 915 | | | | 353 | |
Accounts payable | | | (1,838 | ) | | | 2,721 | |
Accrued payroll and incentives | | | 1,551 | | | | (1,435 | ) |
Accrued profit sharing | | | 768 | | | | 3,488 | |
Accrued expenses and deferred revenue | | | (4,135 | ) | | | 1,119 | |
Accrued warranty | | | 83 | | | | (75 | ) |
Other assets | | | 75 | | | | 206 | |
Other non-current liabilities | | | 34 | | | | (973 | ) |
Net cash provided by operating activities | | | 40,630 | | | | 7,145 | |
Cash flows from investing activities: | | | | | | |
Payments to acquire patents and software | | | (33 | ) | | | (94 | ) |
Proceeds from sale of property and equipment | | | 23 | | | | 46 | |
Payments to acquire property and equipment | | | (32,057 | ) | | | (11,538 | ) |
Net cash used in investing activities | | | (32,067 | ) | | | (11,586 | ) |
Cash flows from financing activities: | | | | | | |
Payments on finance lease obligation | | | (338 | ) | | | (278 | ) |
Dividend distribution | | | (5,536 | ) | | | (4,576 | ) |
Payment of employee withholding tax related to restricted stock units | | | (766 | ) | | | (981 | ) |
Net cash used in financing activities | | | (6,640 | ) | | | (5,835 | ) |
Net increase/(decrease) in cash and cash equivalents | | | 1,923 | | | | (10,276 | ) |
Cash and cash equivalents, beginning of period | | | 53,556 | |
| | 120,728 | |
Cash and cash equivalents, end of period | | $ | 55,479 | | | $ | 110,452 | |
Supplemental disclosure of cash flow information | | | | | | |
Cash paid for: | | | | | | |
Interest, net of amounts capitalized | | $ | 525 | | | $ | 546 | |
Income taxes | | $ | 494 | | | $ | 551 | |
The accompanying notes are an integral part of these condensed consolidated financial statements.
7
SMITH & WESSON BRANDS, INC. AND SUBSIDIARIES
CONDENSED CONSOLIDATED STATEMENTS OF CASH FLOWS - (Continued)
(Unaudited)
Supplemental Disclosure of Non-cash Investing Activities:
| | | | | | | | |
| | For the Three Months Ended July 31, | |
| | 2023 | | | 2022 | |
| | (In thousands) | |
Purchases of property and equipment included in accounts payable | | $ | 17,144 | | | $ | 21,510 | |
Capital lease included in accrued expenses and finance lease payable | | | 734 | | | — | |
The accompanying notes are an integral part of these condensed consolidated financial statements.
8
SMITH & WESSON BRANDS, INC. AND SUBSIDIARIES
NOTES TO CONDENSED CONSOLIDATED FINANCIAL STATEMENTS (UNAUDITED)
For the Three Months Ended July 31, 2023 and 2022
(1) Organization:
We are one of the world’s leading manufacturers and designers of firearms. We manufacture a wide array of handguns (including revolvers and pistols), long guns (including modern sporting rifles), handcuffs, firearm suppressors, and other firearm-related products for sale to a wide variety of customers, including firearm enthusiasts, collectors, hunters, sportsmen, competitive shooters, individuals desiring home and personal protection, law enforcement and security agencies and officers, and military agencies in the United States and throughout the world. We sell our products under the Smith & Wesson, M&P, and Gemtech brands. We manufacture our products at our facilities in Springfield, Massachusetts; Houlton, Maine; and Deep River, Connecticut. During the quarter ended July 31, 2023, we began moving inventory into our new Maryville, Tennessee facility and began distribution activities from there in August 2023. We also sell our manufacturing services to other businesses to attempt to level-load our factories. We sell those services under our Smith & Wesson and Smith & Wesson Precision Components brands. We plan to move our headquarters and certain of our other manufacturing operations to the new facility being constructed in Maryville. See Note 9 — Commitments and Contingencies and Note 10 — Restructuring for more information regarding this plan.
(2) Basis of Presentation:
Interim Financial Information – The condensed consolidated balance sheet as of July 31, 2023, the condensed consolidated statements of income for the three months ended July 31, 2023 and 2022, the condensed consolidated statements of changes in stockholders’ equity for the three months ended July 31, 2023 and 2022, and the condensed consolidated statements of cash flows for the three months ended July 31, 2023 and 2022 have been prepared by us without audit. In our opinion, all adjustments, which include only normal recurring adjustments necessary to fairly present the financial position, results of operations, changes in stockholders’ equity, and cash flows for the three months ended July 31, 2023 and for the periods presented, have been included. All intercompany transactions have been eliminated in consolidation. The consolidated balance sheet as of April 30, 2023 has been derived from our audited consolidated financial statements.
Certain information and footnote disclosures normally included in financial statements prepared in accordance with accounting principles generally accepted in the United States, or GAAP, have been condensed or omitted. These condensed consolidated financial statements should be read in conjunction with the consolidated financial statements and notes thereto included in our Fiscal 2023 Form 10-K. The results of operations for the three months ended July 31, 2023 may not be indicative of the results that may be expected for the fiscal year ending April 30, 2024, or any other period.
(3) Leases:
We lease certain of our real estate, machinery, equipment, and photocopiers under non-cancelable operating and finance lease agreements.
We recognize expenses for our operating lease assets and liabilities at the commencement date based on the present value of lease payments over the lease term. Our leases do not provide an implicit interest rate. We use our incremental borrowing rate based on the information available at the lease commencement date in determining the present value of lease payments. Our lease agreements do not require material variable lease payments, residual value guarantees, or restrictive covenants. For operating leases, we recognize expense on a straight-line basis over the lease term. Tenant improvement allowances are recorded as an offsetting adjustment included in our calculation of the respective right-of-use asset.
Many of our leases include renewal options that enable us to extend the lease term. The execution of those renewal options is at our sole discretion and renewals are reflected in the lease term when they are reasonably certain to be exercised. The depreciable life of assets and leasehold improvements are limited by the expected lease term.
9
SMITH & WESSON BRANDS, INC. AND SUBSIDIARIES
NOTES TO CONDENSED CONSOLIDATED FINANCIAL STATEMENTS (UNAUDITED)
For the Three Months Ended July 31, 2023 and 2022
The amounts of assets and liabilities related to our operating and financing leases as of July 31, 2023 were as follows (in thousands):
| | | | | | |
| | Balance Sheet Caption | | July 31, 2023 | |
Operating Leases | | | | | |
Right-of-use assets | | | | $ | 5,994 | |
Accumulated amortization | | | | | (4,476 | ) |
Right-of-use assets, net | | Other assets | | $ | 1,518 | |
| | | | | |
Current liabilities | | Accrued expenses and deferred revenue | | $ | 996 | |
Non-current liabilities | | Other non-current liabilities | | | 737 | |
Total operating lease liabilities | | | | $ | 1,733 | |
Finance Leases | | | | | |
Right-of-use assets | | | | $ | 41,631 | |
Accumulated depreciation | | | | | (10,014 | ) |
Right-of-use assets, net | | Property, plant, and equipment, net | | $ | 31,617 | |
| | | | | |
Current liabilities | | Accrued expenses and deferred revenue | | $ | 1,466 | |
Non-current liabilities | | Finance lease payable, net of current portion | | | 36,591 | |
Total finance lease liabilities | | | | $ | 38,057 | |
During the three months ended July 31, 2023, we recorded $386,000 of operating lease costs, of which $26,000 related to short-term leases that were not recorded as right-of-use assets. We recorded $566,000 of finance lease amortization and $474,000 of financing lease interest expense for the three months ended July 31, 2023. As of July 31, 2023, the weighted average lease term and weighted average discount rate for our operating leases was 2.8 years and 4.4%, respectively. As of July 31, 2023, the weighted average lease term and weighted average discount rate for our financing leases were 15.1 years and 5.0%, respectively, and consisted primarily of our Missouri distribution center. The building is pledged to secure the amounts outstanding. The depreciable lives of right-of-use assets are limited by the lease term and are amortized on a straight-line basis over the life of the lease.
On October 26, 2017, we entered into (a) a lease agreement with Ryan Boone County, LLC, or the Original Missouri Landlord, concerning certain real property located in Boone County, Missouri on which we had, until recently, been operating a distribution center, or the Missouri Lease, and (b) a guaranty in favor of the Original Missouri Landlord, or the Guaranty. With the completion of the spin-off of our outdoor products and accessories business on August 24, 2020, or the Separation, we entered into a sublease whereby American Outdoor Brands, Inc., our former wholly owned subsidiary, or AOUT, subleases from us 59.0% of our Missouri distribution center under the same terms as the Missouri Lease, or the Missouri Sublease. On July 16, 2022, we entered into an amendment to the Sublease, increasing the leased space to 64.7% of the facility under the same terms as the Missouri Lease. On January 31, 2023, we entered into (i) an assignment and assumption agreement with AOUT, pursuant to which AOUT will assume all of our rights, entitlement, and obligations in, to, and under the Missouri Lease, in each case effective on January 1, 2024, subject to a number of conditions precedent, or the Assignment and Assumption Agreement, and (ii) an amended and restated guaranty in favor of RCS-S&W Facility, LLC, as successor in interest to the Original Missouri Landlord, pursuant to which Smith & Wesson Sales Company was added as a guarantor, or the Amended and Restated Guaranty. We intend to terminate the Missouri Sublease on or around the effective date of the Assignment and Assumption Agreement. As of July 31, 2023, income related to the Missouri Sublease was $581,000, of which $289,000 was recorded in general and administrative expenses and $292,000 was recorded in interest expense, net, in our condensed consolidated statements of income. In addition, we intend to occupy our Connecticut facility through the lease term. As of July 31, 2023, we do not believe there are any indications of impairment relating to these right-of-use assets.
10
SMITH & WESSON BRANDS, INC. AND SUBSIDIARIES
NOTES TO CONDENSED CONSOLIDATED FINANCIAL STATEMENTS (UNAUDITED)
For the Three Months Ended July 31, 2023 and 2022
The following table represents future expected undiscounted cashflows, based on the sublease agreement with AOUT, to be received on an annual basis for the next five years and thereafter, as of July 31, 2023 (in thousands):
| | | | |
Fiscal | | Amount | |
2024 | | $ | 1,917 | |
2025 | | | 3,180 | |
2026 | | | 3,235 | |
2027 | | | 3,292 | |
2028 | | | 3,350 | |
Thereafter | | | 38,906 | |
Total future sublease receipts | | | 53,880 | |
Less amounts representing interest | | | (16,697 | ) |
Present value of sublease receipts | | $ | 37,183 | |
Future lease payments for all our operating and finance leases for succeeding fiscal years is as follows (in thousands):
| | | | | | | | | | | | | | |
|
| | | Operating | | | Financing | | | Total | |
2024 | | | | $ | 1,007 | | | $ | 2,507 | | | $ | 3,514 | |
2025 | | | | | 324 | | | | 3,378 | | | | 3,702 | |
2026 | | | | | 301 | | | | 3,433 | | | | 3,734 | |
2027 | | | | | 272 | | | | 3,490 | | | | 3,762 | |
2028 | | | | | 125 | | | | 3,416 | | | | 3,541 | |
Thereafter | | | | | — | | | | 38,907 | | | | 38,907 | |
Total future lease payments | | | | | 2,029 | | | | 55,131 | | | | 57,160 | |
Less amounts representing interest | | | | | (296 | ) | | | (17,074 | ) | | | (17,370 | ) |
Present value of lease payments | | | | | 1,733 | | | | 38,057 | | | | 39,790 | |
Less current maturities of lease liabilities | | | | | (996 | ) | | | (1,466 | ) | | | (2,462 | ) |
Long-term maturities of lease liabilities | | | | $ | 737 | | | $ | 36,591 | | | $ | 37,328 | |
During the three months ended July 31, 2023, the cash paid for amounts included in the measurement of liabilities and operating cash flows was $1.2 million.
(4) Notes, Loans Payable, and Financing Arrangements:
Credit Facilities — On August 24, 2020, we and certain of our subsidiaries entered into an amended and restated credit agreement, or the Amended and Restated Credit Agreement, with certain lenders, including TD Bank, N.A., as administrative agent; TD Securities (USA) LLC, and Regions Bank, as joint lead arrangers and joint bookrunners; and Regions Bank, as syndication agent. The Amended and Restated Credit Agreement is currently unsecured; however, should any Springing Lien Trigger Event (as defined in the Amended and Restated Credit Agreement) occur, we and certain of our subsidiaries would be required to execute certain documents in favor of TD Bank, N.A., as administrative agent, and the lenders party to such documents would have a legal, valid, and enforceable first priority lien on the collateral described therein.
The Amended and Restated Credit Agreement provides for a revolving line of credit of $100.0 million at any one time, or the Revolving Line. The Revolving Line bears interest at either the Base Rate (as defined in the Amended and Restated Credit Agreement) or the SOFR rate, plus an applicable margin based on our consolidated leverage ratio. The Amended and Restated Credit Agreement also provides a swingline facility in the maximum amount of $5.0 million at any one time (subject to availability under the Revolving Line). Each Swingline Loan (as defined in the Amended and Restated Credit Agreement) bears interest at the Base Rate, plus an applicable margin based on our Adjusted Consolidated Leverage Ratio (as defined in the Amended and Restated Credit Agreement). Subject to the satisfaction of certain terms and conditions described in the Amended and Restated Credit Agreement, we have an option to increase the Revolving Line by an aggregate amount not exceeding $50.0 million. The Revolving Line matures on the earlier of August 24, 2025 or the date that is six months in advance of the earliest maturity of any Permitted Notes (as defined in the Amended and Restated Credit Agreement) under the Amended and Restated Credit Agreement. On April 28, 2023, we entered into an amendment to our existing credit agreement to, among other things, replace LIBOR with SOFR as the interest rate benchmark and amend the definition of “Consolidated Fixed Charge Coverage Ratio” to exclude unfinanced capital expenditures in connection with the Relocation.
11
SMITH & WESSON BRANDS, INC. AND SUBSIDIARIES
NOTES TO CONDENSED CONSOLIDATED FINANCIAL STATEMENTS (UNAUDITED)
For the Three Months Ended July 31, 2023 and 2022
As of July 31, 2023, we had $25.0 million of borrowings outstanding on the Revolving Line, bearing interest at a rate of 6.82%, which is equal to the SOFR rate plus an applicable margin. As a result of the Relocation, for the three months ended July 31, 2023, $443,000 of interest has been capitalized.
The Amended and Restated Credit Agreement contains customary limitations, including limitations on indebtedness, liens, fundamental changes to business or organizational structure, investments, loans, advances, guarantees, and acquisitions, asset sales, dividends, stock repurchases, stock redemptions, and the redemption or prepayment of other debt, and transactions with affiliates. We are also subject to financial covenants, including a minimum consolidated fixed charge coverage ratio and a maximum consolidated leverage ratio. As of July 31, 2023, we were compliant with all required financial covenants.
Letters of Credit — At July 31, 2023, we had outstanding letters of credit aggregating $2.7 million, which included a $1.5 million letter of credit to collateralize our captive insurance company.
(5) Fair Value Measurement:
We follow the provisions of Accounting Standards Codification, or ASC, 820-10, Fair Value Measurements and Disclosures Topic, or ASC 820-10, for our financial assets and liabilities. ASC 820-10 provides a framework for measuring fair value under GAAP and requires expanded disclosures regarding fair value measurements. ASC 820-10 defines fair value as the exchange price that would be received for an asset or paid to transfer a liability (an exit price) in the principal or most advantageous market for the asset or liability in an orderly transaction between market participants on the measurement date. ASC 820-10 also establishes a fair value hierarchy, which requires an entity to maximize the use of observable inputs, where available, and minimize the use of unobservable inputs when measuring fair value.
Financial assets and liabilities recorded on the accompanying condensed consolidated balance sheets are categorized based on the inputs to the valuation techniques as follows:
Level 1 — Financial assets and liabilities whose values are based on unadjusted quoted prices for identical assets or liabilities in an active market that we have the ability to access at the measurement date (e.g., active exchange-traded equity securities, listed derivatives, and most U.S. Government and agency securities).
Our cash and cash equivalents, which are measured at fair value on a recurring basis, totaled $55.5 million and $53.6 million as of July 31, 2023 and April 30, 2023, respectively. The carrying value of our revolving line of credit approximated the fair value as of July 31, 2023. We utilized Level 1 of the value hierarchy to determine the fair values of these assets.
Level 2 — Financial assets and liabilities whose values are based on quoted prices in markets in which trading occurs infrequently or whose values are based on quoted prices of instruments with similar attributes in active markets. Level 2 inputs include the following:
•quoted prices for identical or similar assets or liabilities in non-active markets (such as corporate and municipal bonds which trade infrequently);
•inputs other than quoted prices that are observable for substantially the full term of the asset or liability (such as interest rate and currency swaps); and
•inputs that are derived principally from or corroborated by observable market data for substantially the full term of the asset or liability (such as certain securities and derivatives).
Level 3 — Financial assets and liabilities whose values are based on prices or valuation techniques that require inputs that are both unobservable and significant to the overall fair value measurement. These inputs reflect our judgments about the assumptions a market participant would use in pricing the asset or liability.
We did not have any Level 2 or Level 3 financial assets or liabilities as of July 31, 2023.
12
SMITH & WESSON BRANDS, INC. AND SUBSIDIARIES
NOTES TO CONDENSED CONSOLIDATED FINANCIAL STATEMENTS (UNAUDITED)
For the Three Months Ended July 31, 2023 and 2022
(6) Inventories:
The following table sets forth a summary of inventories, net of reserves, stated at lower of cost or net realizable value, as of July 31, 2023 and April 30, 2023 (in thousands):
| | | | | | | | |
| | July 31, 2023 | | | April 30, 2023 | |
Finished goods | | $ | 99,075 | | | $ | 93,705 | |
Finished parts | | | 53,839 | | | | 65,460 | |
Work in process | | | 5,162 | | | | 6,821 | |
Raw material | | | 12,678 | | | | 11,132 | |
Total inventories | | $ | 170,754 | | | $ | 177,118 | |
(7) Accrued Expenses and Deferred Revenue:
The following table sets forth other accrued expenses as of July 31, 2023 and April 30, 2023 (in thousands):
| | | | | | | | |
| | July 31, 2023 | | | April 30, 2023 | |
Accrued employee benefits | | $ | 3,263 | | | $ | 3,256 | |
Accrued taxes other than income | | | 2,844 | | | | 3,703 | |
Accrued other | | | 2,643 | | | | 4,597 | |
Accrued professional fees | | | 1,989 | | | | 2,596 | |
Accrued distributor incentives | | | 1,762 | | | | 1,640 | |
Current portion of finance lease obligation | | | 1,466 | | | | 1,434 | |
Accrued rebates and promotions | | | 1,078 | | | | 1,649 | |
Current portion of operating lease obligation | | | 996 | | | | 1,274 | |
Total accrued expenses and deferred revenue | | $ | 16,041 | | | $ | 20,149 | |
| | | | | | |
(8) Stockholders’ Equity:
Earnings per Share
The following table provides a reconciliation of the net income amounts and weighted average number of common and common equivalent shares used to determine basic and diluted earnings per share for the three months ended July 31, 2023 and 2022 (in thousands, except per share data):
| | | | | | | | | | | | | | | | | | | | | | | | | | | |
| For the Three Months Ended July 31, | |
| 2023 | | | 2022 | |
| Net | | | | | | Per Share | | | Net | | | | | | Per Share | |
| Income | | | Shares | | | Amount | | | Income | | | Shares | | | Amount | |
Basic earnings | $ | | 3,118 | | | | 46,103 | | | $ | | 0.07 | | | $ | | 3,312 | | | | 45,739 | | | $ | | 0.07 | |
Effect of dilutive stock awards | | — | | | | 448 | | | | — | | | | — | | | | 363 | | | | — | |
Diluted earnings | $ | | 3,118 | | | | 46,551 | | | $ | | 0.07 | | | $ | | 3,312 | | | | 46,102 | | | $ | | 0.07 | |
For the three months ended July 31, 2023 and 2022, the amount of restricted stock units, or RSUs, excluded from the computation of diluted earnings per share was 12,167 and 18,641, respectively, because the effect would be antidilutive.
Incentive Stock and Employee Stock Purchase Plans
In September 2022, our board of directors approved the 2022 Incentive Stock Plan under which employees and non-employees may be granted stock options, restricted stock awards, restricted stock units, stock appreciation rights, bonus stock and awards in lieu of obligations, performance awards, and dividend equivalents.
We have an Employee Stock Purchase Plan, or the ESPP, under which each participant is granted an option to purchase our common stock at a discount on each subsequent exercise date during the offering period (as such terms are defined in the ESPP) in accordance with the terms of the ESPP.
13
SMITH & WESSON BRANDS, INC. AND SUBSIDIARIES
NOTES TO CONDENSED CONSOLIDATED FINANCIAL STATEMENTS (UNAUDITED)
For the Three Months Ended July 31, 2023 and 2022
The total stock-based compensation expense, including stock options, purchases under our ESPP, RSUs, and performance-based RSUs, or PSUs, was $1.3 million and $1.2 million for the three months ended July 31, 2023 and 2022, respectively. We include stock-based compensation expense in cost of sales, sales, marketing and distribution, research and development, and general and administrative expenses.
We grant RSUs to employees and non-employee members of our Board of Directors. The awards are made at no cost to the recipient. An RSU represents the right to receive one share of our common stock and does not carry voting or dividend rights. Except in specific circumstances, RSU grants to employees vest over a period of four years with one-fourth of the units vesting on each anniversary of the grant date. We amortize the aggregate fair value of our RSU grants to compensation expense over the vesting period.
We grant PSUs to our executive officers and, from time to time, certain management employees who are not executive officers. The PSUs vest, and the fair value of such PSUs will be recognized, over the corresponding three-year performance period.
During the three months ended July 31, 2023, we granted an aggregate of 301,483 RSUs, including 175,916 RSUs to non-executive officer employees, 117,724 RSUs to our executive officers, and 7,843 RSUs to a new director. During the three months ended July 31, 2023, we granted 176,583 PSUs to certain of our executive officers. During the three months ended July 31, 2023, we cancelled 158,100 PSUs as a result of the failure to satisfy the performance metric and 5,420 RSUs as a result of the service conditions not being met. In connection with the vesting of RSUs, during the three months ended July 31, 2023, we delivered common stock to our employees, former employees, and directors, including our executive officers, with a total market value of $2.0 million. In connection with a 2019 grant, which vested in fiscal 2023, we delivered market-condition PSUs to certain of our executive officers and a former executive officer with a total market value of $664,000.
During the three months ended July 31, 2022, we granted an aggregate of 229,721 RSUs, including 157,227 RSUs to non-executive officer employees and 72,494 RSUs to our executive officers. During the three months ended July 31, 2022, we granted 108,736 PSUs to certain of our executive officers. During the three months ended July 31, 2022, we cancelled 2,472 RSUs as a result of the service conditions not being met. In connection with the vesting of RSUs, during the three months ended July 31, 2022, we delivered common stock to our employees, former employees, and directors, including our executive officers, with a total market value of $2.2 million. In connection with a 2018 grant, which vested in fiscal 2022, we delivered market-condition PSUs to certain of our executive officers and a former executive officer with a total market value of $1.2 million. In addition, in connection with a 2019 grant, 57,600 PSUs vested to certain of our executive officers and a former executive officer, which resulted from achieving the maximum performance of 200.0% of target for the original 28,800 PSUs granted.
A summary of activity for unvested RSUs and PSUs for the three months ended July 31, 2023 and 2022 is as follows:
| | | | | | | | | | | | | | | | |
| | For the Three Months Ended July 31, | |
| | 2023 | | | 2022 | |
| | | | | Weighted | | | | | | Weighted | |
| | Total # of | | | Average | | | Total # of | | | Average | |
| | Restricted | | | Grant Date | | | Restricted | | | Grant Date | |
| | Stock Units | | | Fair Value | | | Stock Units | | | Fair Value | |
RSUs and PSUs outstanding, beginning of period | | | 932,705 | | | $ | 13.14 | | | | 830,813 | | | $ | 13.30 | |
Awarded | | | 478,066 | | | | 12.10 | | | | 367,257 | | (a) | | 13.70 | |
Released | | | (217,975 | ) | | | 11.00 | | | | (238,444 | ) | | | 12.72 | |
Forfeited | | | (163,520 | ) | | | 10.49 | | | | (2,472 | ) | | | 15.47 | |
RSUs and PSUs outstanding, end of period | | | 1,029,276 | | | $ | 13.53 | | | | 957,154 | | | $ | 13.60 | |
——————————
(a)Includes 28,800 PSUs vested during the three months ended July 31, 2022 in connection with achieving maximum performance targets for the 2019 grants.
As of July 31, 2023, there was $6.4 million of unrecognized compensation expense related to unvested RSUs and PSUs. This expense is expected to be recognized over a weighted average remaining contractual term of 1.9 years.
14
SMITH & WESSON BRANDS, INC. AND SUBSIDIARIES
NOTES TO CONDENSED CONSOLIDATED FINANCIAL STATEMENTS (UNAUDITED)
For the Three Months Ended July 31, 2023 and 2022
(9) Commitments and Contingencies:
Litigation
In January 2018, Gemini Technologies, Incorporated, or Gemini, commenced an action against us in the U.S. District Court for the District of Idaho, or the District Court. The complaint alleges, among other things, that we breached the earn-out and other provisions of the asset purchase agreement and ancillary agreements between the parties in connection with our acquisition of the Gemtech business from Gemini. The complaint seeks a declaratory judgment interpreting various terms of the asset purchase agreement and damages in the sum of $18.6 million. In May 2018, the District Court dismissed the complaint on the grounds of forum non conveniens. In June 2018, Gemini appealed the decision dismissing its complaint to the U.S. Court of Appeals for the Ninth Circuit, or the Ninth Circuit. In July 2019, the Ninth Circuit reversed the dismissal and remanded the case to the District Court to perform a traditional forum non conveniens analysis. In September 2019, the parties stipulated that they do not contest that the venue is proper in the District of Idaho. In November 2019, we filed an answer to Gemini’s complaint and a counterclaim against Gemini and its stockholders at the time of the signing of the asset purchase agreement. Plaintiffs amended their complaint to add a claim of fraud in the inducement. In September 2021, Gemini filed a motion for summary judgment seeking to dismiss our counterclaim. On June 27, 2022, the court denied Gemini's motion for summary judgment. Gemini filed a second motion for summary judgment, and on August 14, 2023, the court again denied Gemini’s motion. We believe the claims asserted in the complaint have no merit, and we intend to aggressively defend this action.
We are a defendant in seven product liability cases and are aware of seven other product liability claims, primarily alleging defective product design, defective manufacturing, or failure to provide adequate warnings. In addition, we are a co-defendant in a case filed in August 1999 by the city of Gary, Indiana, or the City, against numerous firearm manufacturers, distributors, and dealers seeking to recover monetary damages, as well as injunctive relief, allegedly arising out of the misuse of firearms by third parties. In January 2018, the Lake Superior Court, County of Lake, Indiana granted defendants’ Motion for Judgment on the Pleadings, dismissing the case in its entirety. In February 2018, plaintiffs appealed the dismissal to the Indiana Court of Appeals. In May 2019, the Indiana Court of Appeals issued a decision, which affirmed in part and reversed in part, and remanded for further proceedings, the trial court’s dismissal of the City’s complaint. In July 2019, defendants filed a Petition to Transfer jurisdiction to the Indiana Supreme Court. In November 2019, the Indiana Supreme Court denied defendants' petition to transfer and the case was returned to the trial court. Discovery remains ongoing.
We are a defendant in a putative class proceeding before the Ontario Superior Court of Justice in Toronto, Canada that was filed in December 2019. The action claims CAD$50 million in aggregate general damages, CAD$100 million in aggregate punitive damages, special damages in an unspecified amount, together with interest and legal costs. The named plaintiffs are two victims of a shooting that took place in Toronto in July 2018 and their family members. One victim was shot and injured during the shooting. The other victim suffered unspecified injuries while fleeing the shooting. The plaintiffs are seeking to certify a claim on behalf of classes that include all persons who were killed or injured in the shooting and their immediate family members. The plaintiffs allege negligent design and public nuisance. The case has not been certified as a class action. In July 2020, we filed a Notice of Motion for an order striking the claim and dismissing the action in its entirety. In February 2021, the court granted our motion in part, and dismissed the plaintiffs’ claims in public nuisance and strict liability. The court declined to strike the negligent design claim and ordered that the claim proceed to a certification motion. In March 2021, we filed a motion for leave to appeal the court’s refusal to strike the negligent design claim with the Divisional Court, Ontario Superior Court of Justice. In July 2021, plaintiffs filed a motion to stay our motion for leave to appeal with the Divisional Court, on grounds that appeal is premature. In November 2021, the Divisional Court granted plaintiffs' motion, staying our motion for leave to appeal until 30 days after the decision on the balance of plaintiffs' certification motion. Plaintiffs’ certification motion has been extended by the court to January 2024.
In May 2020, we were named in an action related to the Chabad of Poway synagogue shooting that took place in April 2019. The complaint was filed in the Superior Court of the State of California, for the County of San Diego – Central, and asserts claims against us for product liability, unfair competition, negligence, and public nuisance. The plaintiffs allege they were present at the synagogue on the day of the incident and suffered physical and/or emotional injury. The plaintiffs seek compensatory and punitive damages, attorneys’ fees, and injunctive relief. In September 2020, we filed a demurrer and motion to strike, seeking to dismiss plaintiffs’ complaint. In July 2021, the court granted our motion in part, and reversed it in part, ruling that (1) the PLCAA barred plaintiffs’ product liability action; (2) plaintiffs did not have standing to maintain an action under the Unfair Competition Law for personal injury related damages, but gave plaintiffs leave to amend to plead an economic injury; and (3) the PLCAA did not bar plaintiffs’ ordinary negligence and public nuisance actions because plaintiffs had alleged that we violated 18 U.S.C. Section 922(b)(4), which generally prohibits the sale of fully automatic “machineguns.” In August 2021, we filed a Petition for Writ of Mandate in the Court of Appeal of the State of California, Fourth Appellate District, Division One. In September 2021, the Court of Appeal denied our appeal. In February 2022, the court consolidated the case with three related cases, in which we are not a party. In March 2022, the court granted our motion, dismissing
15
SMITH & WESSON BRANDS, INC. AND SUBSIDIARIES
NOTES TO CONDENSED CONSOLIDATED FINANCIAL STATEMENTS (UNAUDITED)
For the Three Months Ended July 31, 2023 and 2022
plaintiffs’ Unfair Competition Law claim, without further leave to amend. Discovery is ongoing. On February 28, 2023, we filed a motion for summary judgment. On May 19, 2023, the court denied our motion for summary judgment without prejudice and allowed plaintiffs time for additional, limited discovery. A hearing on our renewed motion for summary judgment is set for January 12, 2024, and the trial date has been moved to August 30, 2024.
We are a defendant in an action filed in the U.S. District Court for the District of Massachusetts. In August 2021, the Mexican Government filed an action against several U.S.-based firearms manufacturers and a firearms distributor, claiming defendants design, market, distribute, and sell firearms in ways they know routinely arm the drug cartels in Mexico. Plaintiff alleges, among other claims, negligence, public nuisance, design defect, unjust enrichment and restitution against all defendants and violation of the Massachusetts Consumer Protection Act against us alone, and is seeking monetary damages and injunctive relief. In November 2021, defendants filed motions to dismiss plaintiff's complaint. In September 2022, the district court granted defendants’ motions to dismiss. In October 2022, plaintiff filed a notice of appeal with the U.S. Court of Appeals for the First Circuit. Oral argument concerning the appeal was held on July 24, 2023. No decision has issued to date.
In September 2022, we were named as defendants in 12 nearly identical, separate actions related to a shooting in Highland Park, Illinois on July 4, 2022. The complaints were filed in the Circuit Court of the Nineteenth Judicial Circuit in Lake County, Illinois and assert claims against us for negligence and for deceptive and unfair practices under the Illinois Consumer Fraud and Deceptive Business Practices Act. Plaintiffs also name as defendants the website and retailer that sold the firearm, the shooter, and the shooter’s father. The plaintiffs allege they were present at a parade at the time of the incident and suffered physical and/or emotional injury. The plaintiffs seek compensatory damages, attorneys’ fees, and injunctive relief. We filed motions for removal of each case to the U.S. District Court for the Northern District of Illinois. In November 2022, we filed a motion to consolidate the cases for preliminary motion purposes. In December 2022, plaintiffs filed motions to remand the cases back to the state court. On January 20, 2023, we filed our opposition to plaintiffs’ motion to remand.
In December 2022, the City of Buffalo, New York filed a complaint in the Supreme Court of the State of New York, County of Erie, against numerous manufacturers, distributors, and retailers of firearms. Later in December 2022, the City of Rochester, New York filed an almost identical complaint in the Supreme Court of the State of New York, County of Monroe, against the same defendants. The complaints allege violation of New York General Business Law, public nuisance, and deceptive business practices in violation of NY General Business Laws. In January 2023, we filed notices of removal of the cases to the US District Court. On March 24, 2023, defendants filed a motion to stay both cases pending a ruling by the U.S. Court of Appeals for the Second Circuit in the NSSF v. James case. On June 8, 2023, the court granted defendants’ motions to consolidate and to stay pending resolution of the NSSF v. James appeal.
We believe that the various allegations as described above are unfounded, and, in addition, that any incident and any results from them or any injuries were due to negligence or misuse of the firearm by the claimant or a third party.
In March 2022, two plaintiffs, on behalf of a proposed class of current and former employees and temporary workers who worked at our Springfield facility from November 2018 to the present, filed a claim alleging non-payment of wages and overtime in violation of the Massachusetts Wage Act and Massachusetts Fair Wage Act. The case has not been certified as a class action. We believe the claims asserted in the complaint have no merit, and we intend to aggressively defend this action. Mediation was held on June 23, 2023, but the case did not resolve.
In addition, from time to time, we are involved in lawsuits, claims, investigations, and proceedings, including commercial, environmental, premises and employment matters, which arise in the ordinary course of business.
The relief sought in individual cases primarily includes compensatory and, sometimes, punitive damages. Certain of the cases and claims seek unspecified compensatory or punitive damages. In others, compensatory damages sought may range from less than $75,000 to approximately $50.0 million. In our experience, initial demands do not generally bear a reasonable relationship to the facts and circumstances of a particular matter. We believe that our accruals for product liability cases and claims are a reasonable quantitative measure of the cost to us of product liability cases and claims.
We are vigorously defending ourselves in the lawsuits to which we are subject. An unfavorable outcome or prolonged litigation could harm our business. Litigation of this nature also is expensive, time consuming, and diverts the time and attention of our management.
16
SMITH & WESSON BRANDS, INC. AND SUBSIDIARIES
NOTES TO CONDENSED CONSOLIDATED FINANCIAL STATEMENTS (UNAUDITED)
For the Three Months Ended July 31, 2023 and 2022
We monitor the status of known claims and the related product liability accrual, which includes amounts for defense costs for asserted and unasserted claims. After consultation with litigation counsel and a review of the merit of each claim, we have concluded that we are unable to reasonably estimate the probability or the estimated range of reasonably possible losses related to material adverse judgments related to such claims and, therefore, we have not accrued for any such judgments. In the future, should we determine that a loss (or an additional loss in excess of our accrual) is at least reasonably possible and material, we would then disclose an estimate of the possible loss or range of loss, if such estimate could be made, or disclose that an estimate could not be made. We believe that we have provided adequate accruals for defense costs.
At this time, an estimated range of reasonably possible additional losses relating to unfavorable outcomes cannot be made.
Commitments
On September 30, 2021, we announced our plan to move our headquarters and significant elements of our operations to Maryville, Tennessee in 2023, or the Relocation. In connection with the Relocation, we entered into a project agreement, or the Project Agreement, with The Industrial Development Board of Blount County and the cities of Alcoa and Maryville, Tennessee, a public, nonprofit corporation organized and existing under the laws of the state of Tennessee, or the IDB. Pursuant to the Project Agreement, we represented to the IDB that we intend to incur, or cause to be incurred, no less than $120.0 million in aggregate capital expenditures on or before December 31, 2025, create no less than 620 new jobs, and sustain an average hourly wage of at least $25.97 at the facility. Further, pursuant to the Project Agreement, we are required to, among other things, (A) execute a facility lease and an equipment lease with the IDB; (B) cause the construction of the new facility at our sole cost and expense to commence on or before May 31, 2022; (C) incur, or cause to be incurred, aggregate capital expenditures in connection with the construction and equipping of the new facility in an aggregate amount of not less than $120.0 million on or before December 31, 2025; (D) cause the construction of the new facility to be substantially completed and for a certificate of occupancy to be issued therefore on or before December 31, 2023; (E) provide the IDB with a written report certified by one of our authorized officers, not later than January 31 of each year during the period between January 31, 2024 and January 31, 2031; and (F) make certain payments to IDB in the event that our actual capital expenditures, number of employees, or average hourly wage of such employees are less than our projections.
On February 2, 2023, we entered into a design-build agreement with The Christman Company, or Christman, related to the construction of our new distribution center and corporate office headquarters in Maryville, or the Construction Contract. The Construction Contract has an effective date of September 13, 2021 and incorporates the arrangements under which we and Christman have been proceeding. Pursuant to the Construction Contract, Christman is obligated to deliver certain services, including, among others, design phase services and construction phase services, and we are obligated to pay Christman for services performed. The parties to the Construction Contract have jointly agreed that Christman will perform and complete the Work (as defined therein) on a cost-plus basis for a guaranteed maximum price of $114,533,853, including contingencies. When adding the cost of machinery and equipment, we expect to spend between $160.0 million and $170.0 million through the end of fiscal 2024. The Construction Contract includes terms that are customary for contracts of this type, including with respect to indemnification and insurance. The Construction Contract lists certain contract milestones and guaranteed completion dates, and we will be entitled to liquidated damages under certain circumstances. Each party to the Construction Contract is entitled to terminate the Construction Contract under certain circumstances.
As part of the Relocation, on January 31, 2023, we entered into the Assignment and Assumption Agreement and the Amended and Restated Guaranty related to the Missouri facility. Assets associated with our distribution operations in Missouri were evaluated for cost recovery as we began the movement of inventory to the Maryville facility during the fiscal quarter ended July 31, 2023. Consequently, as of July 31, 2023, we recorded an impairment of $2.0 million relating to equipment that we do not currently expect to utilize in the Maryville facility nor to recover the net book value in a sale of the asset. Assets associated with certain of our assembly operations in Massachusetts continue to be fully utilized, and we intend to either move those assets to Maryville at the appropriate time or sell or sublease those assets that will not be moved. Consequently, as of July 31, 2023, we do not believe we had an impairment related to the building or assets. Subsequent to the Relocation, we expect our Springfield facility will continue to remain an important part of our manufacturing activities with significant portions of the operations being unaffected by the Relocation.
In addition, we intend to relocate a portion of our plastic injection molding operations to Maryville, which is expected to begin in our second quarter of 2023, and will evaluate selling the remaining molding operations utilized in our Connecticut operations to a third party. As of July 31, 2023, all plastic injection molding machinery and equipment was being utilized. Therefore, we could not determine an estimated range of reasonably possible losses associated with any impairment of such assets because we have not yet determined which assets may be sold.
17
SMITH & WESSON BRANDS, INC. AND SUBSIDIARIES
NOTES TO CONDENSED CONSOLIDATED FINANCIAL STATEMENTS (UNAUDITED)
For the Three Months Ended July 31, 2023 and 2022
(10) Restructuring:
As a result of the Relocation, $3.9 million and $2.2 million of restructuring charges were recorded in the three months ended July 31, 2023 and 2022, respectively.
The following table summarizes restructuring charges by line item for the three months ended July 31, 2023 and 2022 (in thousands):
| | | | | | | | |
| | For the Three Months Ended July 31, | |
| | 2023 | | | 2022 | |
Cost of sales | | $ | 903 | | | $ | 1,243 | |
Research and development | | | — | | | | 3 | |
Selling, marketing, and distribution | | | 2,195 | | | | 366 | |
General and administrative | | | 814 | | | | 608 | |
Total restructuring charges | | $ | 3,912 | | | $ | 2,220 | |
The components of the restructuring charges recorded in our condensed consolidated statements of income are as follows (in thousands):
| | | | | | | | |
| | For the Three Months Ended July 31, | |
| | 2023 | | | 2022 | |
Severance and employee-related benefits (a)(b) | | $ | 931 | | | $ | 1,527 | |
Relocation (a) | | | 237 | | | | 386 | |
Consulting services | | | 210 | | | | 84 | |
Employee relations | | | 456 | | | | 192 | |
Office rent and equipment | | | 2,078 | | | | 31 | |
Total restructuring charges | | $ | 3,912 | | | $ | 2,220 | |
a)Recorded in accrued payroll and incentives.
b)Amounts reported in Severance and employee-related benefits for the three months ended July 31, 2022 were reclassified to Relocation.
The following table summarizes the activity in the restructuring accrual for the three months ending July 31, 2023 (in thousands):
| | | | | | | | | | | | |
| | Severance and employee-related benefits | | | Relocation | | | Total | |
Accrual at April 30, 2023 | | $ | 10,054 | | | $ | 1,746 | | | $ | 11,800 | |
Charges | | | 931 | | | | 237 | | | | 1,168 | |
Cash payments and settlements | | | (168 | ) | | | (926 | ) | | | (1,094 | ) |
Accrual at July 31, 2023 (a) | | $ | 10,817 | | | $ | 1,057 | | | $ | 11,874 | |
a)Recorded in accrued payroll and incentives.
18
Item 2. Management’s Discussion and Analysis of Financial Condition and Results of Operations
Overview
Please refer to the Management’s Discussion and Analysis of Financial Condition and Results of Operations in our Fiscal 2023 Annual Report and our unaudited condensed consolidated financial statements included in Item 1 of this Quarterly Report on Form 10-Q. This section sets forth key objectives and performance indicators used by us as well as key industry data tracked by us.
First Quarter Fiscal 2024 Highlights
Our operating results for the three months ended July 31, 2023 included the following:
•Net sales were $114.2 million, an increase of $29.8 million, or 35.4%, over the comparable quarter last year.
•Gross margin was 26.6% compared with gross margin of 37.3% for the comparable quarter last year.
•Net income was $3.1 million, or $0.07 per diluted share, slightly lower than the comparable quarter last year.
Results of Operations
Net Sales and Gross Profit – For the Three Months Ended July 31, 2023
The following table sets forth certain information regarding net sales and gross profit for the three months ended July 31, 2023 and 2022 (dollars in thousands):
| | | | | | | | | | | | | | | |
| 2023 | | | 2022 | | | $ Change | | | % Change | |
Handguns | $ | 86,106 | | | $ | 59,367 | | | $ | 26,739 | | | | 45.0 | % |
Long Guns | | 18,782 | | | | 14,105 | | | | 4,677 | | | | 33.2 | % |
Other Products & Services | | 9,355 | | | | 10,922 | | | | (1,567 | ) | | | -14.3 | % |
Total net sales | $ | 114,243 | | | $ | 84,394 | | | $ | 29,849 | | | | 35.4 | % |
Cost of sales | | 83,842 | | | | 52,923 | | | | 30,919 | | | | 58.4 | % |
Gross profit | $ | 30,401 | | | $ | 31,471 | | | $ | (1,070 | ) | | | -3.4 | % |
% of net sales (gross margin) | | 26.6 | % | | | 37.3 | % | | | | | | |
The following table sets forth certain information regarding firearm units shipped by trade channel for the three months ended July 31, 2023 and 2022 (units in thousands):
| | | | | | | | | | | | | | |
Total Units Shipped | | 2023 | | | 2022 | | | # Change | | | % Change |
Handguns | | | 174 | | | | 128 | | | | 46 | | | 35.9% |
Long Guns | | | 39 | | | | 28 | | | | 11 | | | 39.3% |
| | | | | | | | | | | |
Sporting Goods Channel Units Shipped | | 2023 | | | 2022 | | | # Change | | | % Change |
Handguns | | | 161 | | | | 116 | | | | 45 | | | 38.8% |
Long Guns | | | 33 | | | | 25 | | | | 8 | | | 32.0% |
| | | | | | | | | | | |
Professional Channel Units Shipped | | 2023 | | | 2022 | | | # Change | | | % Change |
Handguns | | | 13 | | | | 12 | | | | 1 | | | 8.3% |
Long Guns | | | 6 | | | | 3 | | | | 3 | | | 100.0% |
Sales of our handguns increased $26.7 million, or 45.0%, over the comparable quarter last year, primarily due to increased shipments of our revolvers, increased shipments of newly introduced products (defined as any new SKU not shipped in the comparable quarter last year), which represented 29.9% of handgun sales in the period, as well as a 5% price increase on select products that became effective in the second quarter of fiscal 2023. Handgun unit shipments into the sporting goods channel increased by 38.8% over the comparable quarter last year while overall consumer handgun demand decreased 13.4% (as indicated by adjusted background checks reported in the National Instant Criminal Background Check System, or NICS). During the current quarter, inventory in the channel increased slightly whereas, during the prior year comparable quarter, inventory in the channel declined.
19
Sales of our long guns increased $4.7 million, or 33.2%, over the comparable quarter last year, primarily due to increased shipments of newly introduced products, which represented 62.6% of long gun sales in the period. Long gun unit shipments into our sporting goods channel increased 32.0% over the comparable quarter last year while overall consumer demand for long guns decreased 13.2%, as indicated by NICS. During the current quarter, inventory in the channel increased slightly whereas, during the prior year comparable quarter, inventory in the channel declined.
Other products and services revenue decreased $1.6 million, or 14.3%, from the comparable quarter last year, primarily because of decreased sales of component parts and business-to-business services, partially offset by increased sales of handcuffs and licensing revenue.
New products represented 32.8% of sales for the three months ended July 31, 2023 and included five new pistols, one new long gun, and many new product line extensions.
Gross margin for the three months ended July 31, 2023 was 26.6% compared with gross margin of 37.3% for the comparable quarter last year, primarily because of a combination of unfavorable fixed-cost absorption due to lower production volume, the impact of inflation on raw materials and finished parts, which increased approximately 6.0% over the prior year comparable quarter, the impact of inflation on labor costs, particularly as it relates to entry level positions, and unfavorable inventory reserve adjustments, including amortization of capitalized variances, partially offset by a price increase that became effective in the second quarter of fiscal 2023.
Inventory balances decreased $6.4 million between April 30, 2023 and July 31, 2023. While inventory levels, both internally and in the distribution channel, in excess of demand may negatively impact future operating results, it is difficult to forecast the potential impact of distributor inventories on future revenue and income as demand is impacted by many factors, including seasonality, new product introductions, news events, political events, and consumer tastes. We expect our inventory levels will decline by the end of the fiscal year due to the completion of a significant portion of the operational transition to the new Maryville facility combined with alignment of production capacity to channel inventory and consumer demand.
Operating Expenses
The following table sets forth certain information regarding operating expenses for the three months ended July 31, 2023 and 2022 (dollars in thousands):
| | | | | | | | | | | | | | | |
| 2023 | | | 2022 | | | $ Change | | | % Change | |
Research and development | $ | 1,799 | | | $ | 1,673 | | | $ | 126 | | | | 7.5 | % |
Selling, marketing, and distribution | | 10,040 | | | | 8,027 | | | | 2,013 | | | | 25.1 | % |
General and administrative | | 14,213 | | | | 17,854 | | | | (3,641 | ) | | | -20.4 | % |
Total operating expenses | $ | 26,052 | | | $ | 27,554 | | | $ | (1,502 | ) | | | -5.5 | % |
% of net sales | | 22.8 | % | | | 32.6 | % | | | | | | |
Research and development expenses remained relatively flat compared with the prior year comparable quarter with the slight increase due to additional headcount and sample costs associated with new product development. Selling, marketing, and distribution expenses increased $2.0 million primarily as a result of a $2.0 million impairment on distribution equipment related to the Relocation. General and administrative expenses decreased $3.6 million, primarily because of a decrease of $2.7 million in profit sharing expense and decreased legal-related expenses, partially offset by increased compensation-related expenses. Fiscal 2024 general and administrative expenses were also lower than the prior year comparable quarter due to a change in where sublease-related income is recorded. During the three months ended July 31, 2023, sublease income of $406,000 was recorded in general and administrative expenses whereas, in fiscal 2023, $544,000 was reported in other income/(expense).
Operating Income
The following table sets forth certain information regarding operating income for the three months ended July 31, 2023 and 2022 (dollars in thousands):
| | | | | | | | | | | | | | | |
| 2023 | | | 2022 | | | $ Change | | | % Change | |
Operating income | $ | 4,349 | | | $ | 3,917 | | | $ | 432 | | | | 11.0 | % |
% of net sales (operating margin) | | 3.8 | % | | | 4.6 | % | | | | | | |
20
Operating income for the three months ended July 31, 2023 increased $432,000 over the comparable quarter last year, primarily because of increased sales volumes, decreased profit sharing expenses, and decreased legal-related expenses. These favorable impacts were partially offset by unfavorable fixed cost absorption and unfavorable inventory reserve adjustments, including amortization of capitalized variances.
Income Taxes
The following table sets forth certain information regarding income tax expense for the three months ended July 31, 2023 and 2022 (dollars in thousands):
| | | | | | | | | | | | | | | |
| 2023 | | | 2022 | | | $ Change | | | % Change | |
Income tax expense | $ | 1,431 | | | $ | 845 | | | $ | 586 | | | | 69.3 | % |
% of income from operations (effective tax rate) | | 31.5 | % | | | 20.3 | % | | | | | | 11.2 | % |
Income tax expense increased $586,000 over the comparable quarter last year as a result of higher operating income. Excluding the impact of discrete stock compensation items, the effective tax rate would have been 24.7% and 23.6% for the period ended July 31, 2023 and 2022, respectively.
Net Income
The following table sets forth certain information regarding net income and the related per share data for the three months ended July 31, 2023 and 2022 (dollars in thousands, except per share data):
| | | | | | | | | | | | | | | |
| 2023 | | | 2022 | | | $ Change | | | % Change | |
Income from operations | $ | 3,118 | | | $ | 3,312 | | | $ | (194 | ) | | | -5.9 | % |
Net income per share | | | | | | | | | | | |
Basic | $ | 0.07 | | | $ | 0.07 | | | $ | — | | | | 0.0 | % |
Diluted | $ | 0.07 | | | $ | 0.07 | | | $ | — | | | | 0.0 | % |
Net income for the three months ended July 31, 2023 was flat to the comparable quarter last year for the reasons outlined above.
Liquidity and Capital Resources
Our principal cash requirements are to (1) finance the growth of our operations, including working capital and capital expenditures; (2) fund the Relocation; and (3) return capital to stockholders. Capital expenditures for the Relocation, new product development, and repair and replacement of equipment represent important cash needs.
The following table sets forth certain cash flow information for the three months ended July 31, 2023 and 2022 (dollars in thousands):
| | | | | | | | | | | | | | | | |
| | 2023 | | | 2022 | | | $ Change | | | % Change | |
Operating activities | | $ | 40,630 | | | $ | 7,145 | | | $ | 33,485 | | | | 468.7 | % |
Investing activities | | | (32,067 | ) | | | (11,586 | ) | | | (20,481 | ) | | | -176.8 | % |
Financing activities | | | (6,640 | ) | | | (5,835 | ) | | | (805 | ) | | | -13.8 | % |
Total cash flow | | $ | 1,923 | | | $ | (10,276 | ) | | $ | 12,199 | | | | -118.7 | % |
Operating Activities
On an annual basis, operating activities generally represent the principal source of our cash flows. Cash provided by operating activities was $40.6 million for the three months ended July 31, 2023 compared with $7.1 million of cash generated for the three months ended July 31, 2022. Cash provided by operating activities for the three months ended July 31, 2023 was positively impacted by a $52.2 million incremental decrease in inventory resulting from increased sales and lower production, partially offset by a $11.9 million incremental increase in accounts receivable due to increased sales, and a $5.3 million incremental decrease in accrued expenses due to a reduction in federal excise tax payable.
21
Investing Activities
Cash used in investing activities increased $20.5 million for the three months ended July 31, 2023 compared with the prior year comparable period. We paid $32.1 million for capital expenditures for the three months ended July 31, 2023, of which $30.4 million related to the Relocation, including $443,000 for capitalized interest. Excluding payments related to the Relocation, we expect to spend between $20.0 million and $25.0 million on capital expenditures in fiscal 2024.
We expect to spend between $70.0 million and $75.0 million on capital expenditures related to the Relocation in fiscal 2024, of which $50.0 million to $55.0 million is for the construction of the facility.
Financing Activities
Cash used in financing activities was $6.6 million for the three months ended July 31, 2023, which was primarily the result of a $5.5 million dividend distribution. Cash used in financing activities was $5.8 million for the three months ended July 31, 2022, which was primarily the result of a $4.6 million dividend distribution.
Finance Lease – We are a party to a material finance lease, the Missouri Lease, which is a $46.2 million lease for our Missouri distribution center that has an effective interest rate of approximately 5.0% and is payable in 240 monthly installments through fiscal 2039. The building is pledged to secure the amounts outstanding. During fiscal 2024, we paid approximately $305,000 in principal payments relating to the Missouri Lease. With the completion of the Separation, we entered into the Missouri Sublease. On July 16, 2022, we entered into an amendment to the Missouri Sublease, increasing the subleased space to 64.7% of the facility under the same terms as the Missouri Lease. On January 31, 2023, we entered into the Assignment and Assumption Agreement and the Amended and Restated Guaranty. We intend to terminate the Missouri Sublease on or around the effective date of the Assignment and Assumption Agreement. We recorded $581,000 of income related to the Missouri Sublease, of which $289,000 was recorded in general and administrative expenses and $292,000 was recorded in interest income in our condensed consolidated statements of income.
Credit Facilities — We maintain an unsecured revolving line of credit with TD Bank, N.A. and other lenders, or the Lenders, which includes availability up to $100.0 million at any one time, or the Revolving Line. The Revolving Line provides for availability for general corporate purposes, with borrowings to bear interest at either the Base Rate or SOFR rate, plus an applicable margin based on our consolidated leverage ratio, as of July 31, 2023. The credit agreement also provides a swingline facility in the maximum amount of $5.0 million at any one time (subject to availability under the Revolving Line). Each swingline loan bears interest at the Base Rate, plus an applicable margin based on our consolidated leverage ratio. In response to a Springing Lien Triggering Event (as defined in the credit agreement), we would be required to enter into certain documents that create in favor of TD Bank, N.A., as administrative agent, and the lenders party to such documents as legal, valid, and enforceable first priority lien on the collateral described therein. Subject to the satisfaction of certain terms and conditions described in the credit agreement, we have an option to increase the Revolving Line by an aggregate amount not exceeding $50.0 million. The Revolving Line matures on the earlier of August 24, 2025, or the date that is six months in advance of the earliest maturity of any permitted notes under the credit agreement. On April 28, 2023, we entered into an amendment to our existing credit agreement to, among other things, replace LIBOR with SOFR as the interest rate benchmark and amend the definition of “Consolidated Fixed Charge Coverage Ratio” to exclude unfinanced capital expenditures in connection with the Relocation.
As of July 31, 2023, we had $25.0 million of borrowings outstanding on the Revolving Line, bearing interest at a rate of 6.82%, which was equal to the SOFR rate plus an applicable margin.
The credit agreement for our credit facility contains financial covenants relating to maintaining maximum leverage and minimum debt service coverage. We were in compliance with all debt covenants as of July 31, 2023.
Dividends — In June 2023, our Board of Directors authorized a regular quarterly dividend for stockholders of $0.12 per share. The current dividend will be for stockholders of record as of market close on September 21, 2023 and will be payable on October 5, 2023.
Our future capital requirements will depend on many factors, including net sales, the timing and extent of spending to support product development efforts, the expansion of sales and marketing activities, the timing of introductions of new products and enhancements to existing products, the costs to ensure access to adequate manufacturing capacity, and costs related to the Relocation. Further equity or debt financing may not be available to us on acceptable terms or at all. If sufficient funds are not available or are not available on acceptable terms, our ability to take advantage of unexpected business opportunities or to respond to competitive pressures could be limited or severely constrained.
22
As of July 31, 2023, we had $55.5 million in cash and cash equivalents on hand. Based upon our current working capital position, current operating plans, and expected business conditions, we believe that our existing capital resources and credit facilities will be adequate to fund our operations, including our finance leases and other commitments, for the next 12 months.
Other Matters
Critical Accounting Policies
The preparation of condensed consolidated financial statements in conformity with GAAP requires us to make estimates and assumptions that affect the reported amounts of assets and liabilities at the date of the financial statements and the reported amounts of revenue and expenses during the reporting periods. Significant accounting policies are disclosed in Note 2 of the Notes to the Consolidated Financial Statements in our Fiscal 2023 Annual Report. The most significant areas involving our judgments and estimates are described in Management’s Discussion and Analysis of Financial Condition and Results of Operations in our Fiscal 2023 Annual Report, to which there have been no material changes. Actual results could differ from our estimates.
Recent Accounting Pronouncements
The nature and impact of recent accounting pronouncements, if any, is discussed in Note 2—Basis of Presentation to our condensed consolidated financial statements included elsewhere in this report, which is incorporated herein by reference.
Item 3. Quantitative and Qualitative Disclosures About Market Risk
During the period ended July 31, 2023, we did not enter into or transact any forward option contracts nor did we have any forward contracts outstanding.
Item 4. Controls and Procedures
Evaluation of Disclosure Controls and Procedures
Under the supervision and with the participation of our management, including our Chief Executive Officer and Chief Financial Officer, we conducted an evaluation of the effectiveness of the design and operation of our disclosure controls and procedures (as defined in Rules 13a-15(e) and 15d-15(e) under the Securities Exchange Act of 1934, as amended, or the Exchange Act). Based on this evaluation, our Chief Executive Officer and Chief Financial Officer concluded that, as of July 31, 2023, our disclosure controls and procedures (as defined in Rules 13a-15(e) and 15d-15(e) under the Exchange Act) were effective to ensure that information required to be disclosed by us in reports that we file or submit under the Exchange Act was recorded, processed, summarized, and reported within the time periods specified in SEC rules and forms, and that such information is accumulated and communicated to our management, including our Chief Executive Officer and Chief Financial Officer, as appropriate, to allow timely decisions regarding required disclosure.
There was no change in our internal control over financial reporting during the period covered by this Quarterly Report on Form 10-Q that has materially affected, or is reasonably likely to materially affect, our internal control over financial reporting.
23
PART II — OTHER INFORMATION
Item 1. Legal Proceedings
The nature of legal proceedings against us is discussed in Note 9—Commitments and Contingencies to our condensed consolidated financial statements included elsewhere in this report, which is incorporated herein by reference.
Item 2. Unregistered Sales of Equity Securities and Use of Proceeds
As of July 31, 2023, we had no authorized share repurchase programs.
Item 5. Other Information
Rule 10b5-1 Trading Plans
The adoption or termination of contracts, instructions, or written plans for the purchase and sale of our securities by our Section 16 officers and directors for the three months ended July 31, 2023, each of which is intended to satisfy the affirmative defense conditions of Rule 10b5-1(c) under the Exchange Act, or a Rule 10b5-1 Plan, were as follows:
| | | | | | | | | | | | |
Name | | Title | | Action | | Date Adopted | | Expiration Date | | Aggregate # of Securities to be Purchased/Sold | |
Robert L. Scott | | Director | | Adoption of Rule 10b5-1 Plan | | June 28, 2023 | | March 29, 2024 | | | 12,000 | |
Robert L. Scott, one of our directors, entered into a Rule 10b5-1 Plan on June 28, 2023. Mr. Scott's Rule 10b5-1 Plan provides for the potential sale of up to 12,000 shares of our common stock and expires on March 29, 2024, or upon the earlier completion of all the transactions authorized thereunder.
During the three months ended July 31, 2023, none of our directors or officers adopted or terminated a "non-Rule 10b5-1 trading arrangement" (as defined in Item 408 of Regulation S-K).
Item 6. Exhibits
The exhibits listed on the Index to Exhibits (immediately preceding the signatures section of this Quarterly Report on Form 10-Q) are included herewith or incorporated herein by reference.
24
INDEX TO EXHIBITS
___________________________________________
(1) Incorporated by reference to the Registrant's Form 8-K filed with the SEC on June 30, 2023.
25
SIGNATURES
Pursuant to the requirements of the Securities Exchange Act of 1934, the registrant has duly caused this report to be signed on its behalf by the undersigned thereunto duly authorized.
| | | | |
|
| SMITH & WESSON BRANDS, INC. a Nevada corporation |
| | |
Date: September 7, 2023 |
| By: |
| /s/ Mark P. Smith |
|
|
|
| Mark P. Smith |
| | | | President and Chief Executive Officer |
| | | | |
Date: September 7, 2023 |
| By: |
| /s/ Deana L. McPherson |
|
|
|
| Deana L. McPherson |
|
|
|
| Executive Vice President, Chief Financial Officer, Treasurer, and Assistant Secretary |
26