Energy Services of America 10Q/A 2022 Q1 Quarterly report (amended)

UNITED STATES

SECURITIES AND EXCHANGE COMMISSION

WASHINGTON, D.C. 20549

FORM 10-Q/A

(Amendment No. 1)

(Mark One)



☒	Quarterly report pursuant to Section 13 or 15(d) of the Securities Exchange Act of 1934

For the quarterly period ended December 31, 2022.

Energy Services of America Corporation

(Exact Name of Registrant as Specified in Its Charter)


Delaware		20-4606266
(State or Other Jurisdiction of Incorporation or Organization)		(I.R.S. Employer Identification Number)


75 West 3^rd Ave., Huntington, West Virginia		25701
(Address of Principal Executive Office)		(Zip Code)

(304) 522-3868

(Registrant’s Telephone Number Including Area Code)

Securities Registered Pursuant to Section 12(b) of the Act:

Title of Each Class		Trading Symbols		Name of Each Exchange On Which Registered
Common Stock, Par Value $0.0001		ESOA		The Nasdaq Stock Market LLC

Indicate by check mark whether the Registrant (1) has filed all reports required to be filed by Section 13 or 15(d) of the Securities Exchange Act of 1934 during the preceding 12 months (or for such shorter period that the Registrant was required to file such reports) and (2) has been subject to such requirements for the past 90 days. YES ☒ NO ☐.

Indicate by check mark whether the registrant has submitted electronically every Interactive Data File required to be submitted pursuant to Rule 405 of Regulation S-T during the preceding 12 months (or for such shorter period that the registrant was required to submit such files). YES ☒ NO ☐.

Indicate by check mark whether the registrant is a large accelerated filer, an accelerated filer, a non-accelerated filer, a smaller reporting company, or an emerging growth company. See the definition of “large accelerated filer,” “accelerated filer”, “smaller reporting company”, or an “emerging growth company” in Rule 12b-2 of the Exchange Act. (Check one):


Large accelerated filer	☐	Accelerated filer	☐

Non-accelerated filer	☒	Smaller reporting company	☒

		Emerging growth company	☐

If an emerging growth company, indicate by check mark if the registrant has elected not to use the extended transition period for complying with any new or revised financial accounting standards provided pursuant to Section 13(a) of the Exchange Act. ☐

Indicate by check mark whether the Registrant is a shell company (as defined in Rule 12b-2 of the Exchange Act). YES ☐ NO ☒

As of February 13, 2023, there were 16,667,185 outstanding shares of the Registrant’s Common Stock.

Table of Contents

EXPLANATORY NOTE

Energy Services of America Corporation (“Energy Services” or the “Company”) is filing this Amendment No. 1 to the Quarterly Report on Form 10-Q/A (the “Amendment”) to amend its Quarterly Report on Form 10-Q for the three months ended December 31, 2022, originally filed with the U.S. Securities and Exchange Commission (the “SEC”) on February 13, 2023 (the “Original Report”). In filing this amendment, the Company is restating its previously issued unaudited financial statements for the three months ended December 31, 2022 and 2021 to account for misstatements related to accounting for loans under the Paycheck Protection Program (“PPP”). Those previously issued unaudited financial statements should no longer be relied upon. Except as described below, all other information in, and the exhibits to, the Original Report remain unchanged. This Amendment speaks as of the date of the Original Report and the Company has not updated the Original Report to reflect events occurring subsequent to the date of the Original Report. All information contained in this Amendment is subject to updating and supplementing as provided in our reports filed with the SEC subsequent to the date of the Original Report. Accordingly, this Amendment should be read in conjunction with our filings made with the SEC subsequent to the Original Report.

Background and Effects of the Restatement

On May 12, 2023, the audit committee of the Board of Directors of Energy Services of America, after considering the recommendation of management, concluded: that (a) the Company’s previously issued audited consolidated financial statements for the fiscal years ended September 30, 2022 and 2021, and the related reports of its independent registered public accounting firm, Baker Tilly US, LLP (“Baker Tilly”), included in the Company’s annual reports on Form 10-K for the fiscal years ended September 30, 2022 and 2021, and (b) the Company’s unaudited consolidated financial statements for the periods ended June 30, 2021, December 31, 2021, March 31, 2022, June 30, 2022 and December 31, 2022 as reported in the Company’s quarterly reports on Form 10-Q for those periods (together, the “Reports”) should no longer be relied upon and have been restated.

Due to the economic uncertainties created by COVID-19 and limited operating funds available, the Company applied for loans under the Paycheck Protection Program (“PPP”). On April 15, 2020, the Company and its subsidiaries, C.J. Hughes Construction Company, Inc., Contractors Rental Corporation and Nitro Construction Services, Inc., entered into separate PPP notes effective April 7, 2020, with United Bank as the lender (“Lender”) in an aggregate principal amount of $13.1 million pursuant to the PPP (collectively, the “PPP Loans”). In a special meeting held on April 27, 2020, the Board of Directors of the Company unanimously voted to return $3.3 million of the PPP Loans after discussing the financing needs of the Company and subsidiaries. That left the Company and subsidiaries with $9.8 million in PPP Loans to fund operations. During fiscal year 2021, the Company received notice that The Small Business Administration (“SBA”) had granted forgiveness of the $9.8 million of PPP Loans and the SBA repaid the Lender in full. The forgiveness was recorded as other income for the fiscal year ended September 30, 2021.

The Company has identified the misstatements described below, and this Amendment restates the previously issued unaudited financial statements of the Company and certain other related disclosures at or for the three months ended December 31, 2022 and 2021 that were included in the Original Report. The Company has recorded a short-term borrowing due to the SBA inquiry for the full $9.8 million, plus accrued interest for all periods presented.

Tables for the income statement impact “As previously reported” and “restated” for Payroll Protection Program loan forgiveness and interest expense for the three months ended December 31, 2022 and 2021 are below:


	Three Months Ended December 31, 2022
	As Previously
	Reported		Restated		Change
Interest expense	$	474,284	$	499,428	$	25,144
Net income		163,518		138,374		(25,144)

Table of Contents


	Three Months Ended December 31, 2021
	As Previously
	Reported		Restated		Change
Interest expense	$	197,559	$	222,703	$	25,144
Net income		1,170,980		1,145,836		(25,144)

Tables for the balance sheet impact “As previously reported” and “restated” for lines of credit and short-term borrowings at September 30, 2022 and 2021 and at December 31, 2022 and December 31, 2021 are below:


	September 30, 2022
	As Previously
	Reported		Restated		Change
Lines of credit and short-term borrowings	$	13,080,320	$	23,164,851	$	10,084,531
Shareholders' equity		38,325,075		28,240,544		(10,084,531)


	September 30, 2021
	As Previously
	Reported		Restated		Change
Lines of credit and short-term borrowings	$	5,040,250	$	15,025,023	$	9,984,773
Shareholders' equity		34,637,046		24,652,273		(9,984,773)


	December 31, 2022
	As Previously
	Reported		Restated		Change
Lines of credit and short-term borrowings	$	12,500,000	$	22,609,675	$	10,109,675
Shareholders' equity		38,488,593		28,378,918		(10,109,675)


	December 31, 2021
	As Previously
	Reported		Restated		Change
Lines of credit and short-term borrowings	$	4,500,000	$	14,509,917	$	10,009,917
Shareholders' equity		34,597,764		24,587,847		(10,009,917)

Disclosure Controls and Procedures

Management re-evaluated the effectiveness of our disclosure controls and procedures as of December 31, 2022 and has concluded that our disclosure controls and procedures were not effective as of that date because of the identification of a material weakness. A material weakness is a deficiency, or a combination of deficiencies, in internal control over financial reporting, such that there is a reasonable possibility that a material misstatement of a company’s annual or interim financial reports will not be prevented or detected on a timely basis. The existence of one or more material weaknesses precludes a conclusion by management that a company’s disclosure controls and procedures are effective. Management has taken, and is taking additional steps, as described under “Remediation Plan and Status” in Item 4 of Part I of this Amendment, to remediate the material weakness in our internal control over financial reporting. For more information regarding the restatement and its impact on our financial statements, refer to Note 3 Restatement of Previously Issued Financial Statements of the Notes to the unaudited Consolidated Financial Statements included within this Amendment.

Items Amended in this Filing

This Amendment amends and restates the following Items 1, 2 and 4 appearing in Part I, and Item 6 appearing in Part II. Except as noted above, no other information in our Original Report is amended and is repeated herein solely for the reader’s convenience.

Table of Contents


Part 1: Financial Information

Item 1. Financial Statements (Unaudited):

Consolidated Balance Sheets		1

Consolidated Statements of Income		2

Consolidated Statements of Cash Flows		3

Consolidated Statements of Changes in Shareholders’ Equity		4

Notes to Unaudited Consolidated Financial Statements		5

Item 2. Management’s Discussion and Analysis of Financial Condition and Results of Operations		18

Item 3. Quantitative and Qualitative Disclosures About Market Risk		34

Item 4. Controls and Procedures		34

Part II: Other Information

Item 1. Legal Proceedings		36

Item 1A. Risk Factors		36

Item 2. Unregistered Sales of Equity Securities and Use of Proceeds		36

Item 6. Exhibits		37

Signatures		38

Table of Contents

Part 1. Financial Information

Item 1. Financial Statements (Unaudited):

Energy Services of America Corporation

Consolidated Balance Sheets

Unaudited


	As Restated		As Restated
	December 31,		September 30,
	2022		2022
Assets
Current assets
Cash and cash equivalents	$	7,530,907	$	7,427,474
Accounts receivable-trade		35,357,058		38,525,223
Allowance for doubtful accounts		(55,538)		(70,310)
Retainages receivable		4,989,451		4,443,679
Other receivables		13,699		10,866
Contract assets		14,397,681		16,109,593
Prepaid expenses and other		3,170,481		3,945,968
Total current assets		65,403,739		70,392,493

Property, plant and equipment, at cost		75,859,708		73,736,433
less accumulated depreciation		(42,647,308)		(41,074,646)
Total property and equipment, net		33,212,400		32,661,787

Right-of-use assets-operating lease		1,478,781		1,611,321
Intangible assets, net		3,740,910		3,873,690
Goodwill		4,087,554		4,087,554
Total assets	$	107,923,384	$	112,626,845

Liabilities and shareholders’ equity
Current liabilities
Current maturities of long-term debt	$	4,575,060	$	4,060,016
Lines of credit and short-term borrowings		22,609,675		23,164,851
Current maturities of operating lease liabilities		506,606		588,653
Accounts payable		14,984,022		20,314,408
Accrued expenses and other current liabilities		8,814,256		11,266,008
Contract liabilities		8,611,883		6,027,578
Total current liabilities		60,101,502		65,421,514

Long-term debt, less current maturities		14,444,751		13,494,084
Long-term operating lease liabilities, less current maturities		965,012		1,015,624
Deferred tax liability		4,033,201		4,455,079
Total liabilities		79,544,466		84,386,301

Shareholders’ equity


Common stock, $.0001 par value Authorized 50,000,000 shares, 17,885,615 issued and 16,667,185 outstanding at December 31, 2022 and September 30, 2022		1,789		1,789

Treasury stock, 1,218,430 shares at December 31, 2022 and September 30, 2022		(122)		(122)

Additional paid in capital		60,508,350		60,508,350
Retained deficit		(32,131,099)		(32,269,473)

Total shareholders’ equity		28,378,918		28,240,544

Total liabilities and shareholders’ equity	$	107,923,384	$	112,626,845

The Accompanying Notes are an Integral Part of These Financial Statements

Table of Contents

Energy Services of America Corporation

Consolidated Statements of Income

Unaudited


	As Restated		As Restated
	Three Months Ended		Three Months Ended
	December 31,		December 31,
	2022		2021
Revenue	$	60,042,585	$	42,659,125

Cost of revenues		54,056,323		37,350,752

Gross profit		5,986,262		5,308,373

Selling and administrative expenses		5,316,138		3,632,595
Income from operations		670,124		1,675,778

Other income (expense)
Interest income		72		576
Other nonoperating expense		(80,663)		(153,428)
Interest expense		(499,428)		(222,703)
(Loss) gain on sale of equipment		(31,343)		339,896
		(611,362)		(35,659)

Income before income taxes		58,762		1,640,119

Income tax (benefit) expense		(79,612)		494,283

Net income	$	138,374	$	1,145,836



Weighted average shares outstanding-basic		16,667,185		16,247,898

Weighted average shares-diluted		16,667,185		16,247,898

Earnings per share-basic	$	0.01	$	0.07

Earnings per share-diluted	$	0.01	$	0.07

The Accompanying Notes are an Integral Part of These Financial Statements

Table of Contents

Energy Services of America Corporation

Consolidated Statements of Cash Flows

Unaudited


	As Restated		As Restated
	Three Months Ended		Three Months Ended
	December 31,		December 31,
	2022		2021
Cash flows from operating activities:

Net income, as restated	$	138,374	$	1,145,836
Adjustments to reconcile net income to net cash provided by operating activities:
Accreted interest on PPP loans		25,144		25,144
Depreciation expense		1,762,322		1,304,496
Loss (gain) on sale of equipment		31,343		(339,896)
Deferred income tax benefit		(421,878)		(367,010)
Amortization of intangible assets		132,780		119,456
Accreted interest on notes payable		10,599		—
Decrease (increase) in accounts receivable		3,153,393		(4,265,751)
Increase in retainage receivable		(545,772)		(551,585)
(Increase) decrease in other receivables		(2,833)		494,771
Decrease in contract assets		1,711,912		2,815,751
Decrease in prepaid expenses and other		775,487		750,846
(Decrease) increase in accounts payable		(5,330,386)		58,226
(Decrease) increase in accrued expenses and other current liabilities		(2,451,871)		837,579
Increase in contract liabilities		2,584,305		4,375,775
Net cash provided by operating activities		1,572,919		6,403,638

Cash flows from investing activities:
Investment in property and equipment		(2,348,901)		(942,703)
Proceeds from sales of property and equipment		92,815		463,862
Net cash used in investing activities		(2,256,086)		(478,841)

Cash flows from financing activities:
Preferred stock redemption		—		(1,262,750)
Borrowings on lines of credit and short-term debt, net of (repayments)		(580,320)		(540,250)
Proceeds from long-term debt		3,100,000		—
Principal payments on long-term debt		(1,733,080)		(1,215,390)
Net cash provided by (used in) financing activities		786,600		(3,018,390)
Increase in cash and cash equivalents		103,433		2,906,407
Cash and cash equivalents beginning of period		7,427,474		8,226,739
Cash and cash equivalents end of period	$	7,530,907	$	11,133,146

Supplemental schedule of noncash investing and financing activities:
Purchases of property & equipment under financing agreements	$	88,192	$	240,145
Par value of common stock issued from preferred stock conversion	$	—	$	263

Supplemental disclosures of cash flows information:
Cash paid during the year for:
Interest	$	472,960	$	186,580

The Accompanying Notes are an Integral Part of These Financial Statements

Table of Contents

Energy Services of America Corporation

Consolidated Statements of Changes in Shareholders’ Equity

For the three months ended December 31, 2022 and 2021

Unaudited


										Total
	Common Stock			Additional Paid		Retained		Treasury		Shareholders’
	Shares	Amount		in Capital		Deficit		Stock		Equity

Balance at September 30, 2022, as restated	16,667,185	$	1,789	$	60,508,350	$	(32,269,473)	$	(122)	$	28,240,544

Net income, as restated	—		—		—		138,374		—		138,374

Balance at December 31, 2022, as restated	16,667,185	$	1,789	$	60,508,350	$	(32,131,099)	$	(122)	$	28,378,918


										Total
	Common Stock			Additional Paid		Retained		Treasury		Shareholders’
	Shares	Amount		in Capital		Deficit		Stock		Equity
Balance at September 30, 2021, as restated	13,621,406	$	1,484	$	60,670,699	$	(36,019,788)	$	(122)	$	24,652,273

Net income, as restated	—		—		—		1,145,836		—		1,145,836

Preferred share redemption, net of accrued dividends at September 30, 2021	—		—		(1,210,525)		—		—		(1,210,525)

Preferred share conversion	2,626,492		263		—		—		—		263

Balance at December 31, 2021, as restated	16,247,898	$	1,747	$	59,460,174	$	(34,873,952)	$	(122)	$	27,214,339

The Accompanying Notes are an Integral Part of These Financial Statements

Table of Contents

ENERGY SERVICES OF AMERICA CORPORATION

NOTES TO UNAUDITED CONSOLIDATED FINANCIAL STATEMENTS

1. BUSINESS AND ORGANIZATION

Energy Services of America Corporation (“Energy Services” or the “Company”), formed in 2006, is a contractor and service company that operates primarily in the mid-Atlantic and central regions of the United States and provides services to customers in the natural gas, petroleum, water distribution, automotive, chemical, and power industries. For the gas industry, the Company is primarily engaged in the construction, replacement and repair of natural gas pipelines and storage facilities for utility companies and private natural gas companies. Energy Services is involved in the construction of both interstate and intrastate pipelines, with an emphasis on the latter. For the oil industry, the Company provides a variety of services relating to pipeline, storage facilities and plant work. For the power, chemical, and automotive industries, the Company provides a full range of electrical and mechanical installations and repairs including substation and switchyard services, site preparation, equipment setting, pipe fabrication and installation, packaged buildings, transformers, and other ancillary work with regards thereto. Energy Services’ other services include liquid pipeline construction, pump station construction, production facility construction, water and sewer pipeline installations, various maintenance and repair services and other services related to pipeline construction. The Company has also added the ability to install residential, commercial, and industrial solar systems and perform civil and general contracting services.

C.J. Hughes Construction Company, Inc. (“C.J. Hughes”), a wholly owned subsidiary of the Company, is a general contractor primarily engaged in pipeline construction for utility companies. Contractors Rental Corporation (“Contractors Rental”), a wholly owned subsidiary of C.J. Hughes, provides union building trade employees for projects managed by C.J. Hughes.

Nitro Construction Services, Inc. (“Nitro”), a wholly owned subsidiary of C.J. Hughes, provides electrical, mechanical, HVAC/R, solar installation, and fire protection services to customers primarily in the automotive, chemical, and power industries. Revolt Energy, LLC and Nitro Electric Company, LLC are newly formed, wholly owned subsidiaries of Nitro. Pinnacle Technical Solutions, Inc. (“Pinnacle”), a wholly owned subsidiary of Nitro, operates as a data storage facility within Nitro’s office building. Pinnacle is supported by Nitro and has no employees of its own. All C.J. Hughes, Nitro, and Contractors Rental construction personnel are union members of various related construction trade unions and are subject to collective bargaining agreements that expire at varying time intervals.

West Virginia Pipeline, Inc. (“West Virginia Pipeline” or “WVP”), a wholly owned subsidiary of Energy Services, operates as a gas and water distribution contractor primarily in southern West Virginia. The employees of West Virginia Pipeline are non-union and are managed independently of the Company’s union subsidiaries.

SQP Construction Group, Inc. (“SQP”), a wholly owned subsidiary of Energy Services, operates as a general contractor primarily in West Virginia. SQP engages in the construction and renovation of buildings and other civil construction projects for state and local government agencies and commercial customers. As a general contractor, SQP manages the overall construction project and subcontracts most of the work. The employees of SQP are non-union and are managed independently of the Company’s union subsidiaries.

Tri-State Paving & Sealcoating, Inc. (“TSP” or “Tri-State Paving”), a wholly owned subsidiary of Energy Services, completed the acquisition of substantially all of the assets of Tri-State Paving & Sealcoating, LLC (“Tri-State Paving, LLC”) on April 29, 2022. Tri-State Paving provides utility paving services to water distribution customers in the Charleston, West Virginia, Lexington, Kentucky, and Chattanooga, Tennessee markets. The employees of TSP are non-union and are managed independently of the Company’s union subsidiaries.

Ryan Construction Services Inc. (“Ryan Construction” or “RCS”), a wholly owned subsidiary of Energy Services, formed in August 2022 in connection with the acquisition of substantially all of the assets of Ryan Environmental, LLC and Ryan Environmental Transport, LLC, provides directional drilling services for broadband service providers along with offering natural gas distribution services, cathodic protection and corrosion prevention services, and civil construction services. Ryan Construction operates primarily in West Virginia and Pennsylvania. The employees of RCS are non-union and are managed independently of the Company’s union subsidiaries.

Table of Contents

Interim Financial Statements

The accompanying unaudited consolidated financial statements have been prepared pursuant to the rules and regulations of the Securities and Exchange Commission (“SEC”) and should be read in conjunction with the Company’s audited consolidated financial statements and footnotes thereto for the years ended September 30, 2022, and 2021 included in the Company’s Amendment No. 1 to the Company’s Annual Report on Form 10-K/A filed with the SEC on May 31, 2023. Certain information and footnote disclosures normally included in annual financial statements prepared in accordance with accounting principles generally accepted in the United States of America (“U.S. GAAP”) have been omitted pursuant to the interim financial reporting rules and regulations of the SEC. The financial statements reflect all adjustments (consisting primarily of normal recurring adjustments) that are, in the opinion of management, necessary for a fair presentation of the Company’s financial position and results of operations. The operating results for the three months ended December 31, 2022, and 2021 are not necessarily indicative of the results to be expected for the full year or any other interim period.

Principles of Consolidation

The consolidated financial statements of Energy Services include the accounts of Energy Services, its wholly owned subsidiaries West Virginia Pipeline, SQP, Ryan Construction, Tri-State Paving and C.J. Hughes and its subsidiaries. All significant intercompany accounts and transactions have been eliminated in the consolidation. Unless the context requires otherwise, references to Energy Services include Energy Services, West Virginia Pipeline, SQP, Ryan Construction, Tri-State Paving and C.J. Hughes and its subsidiaries.

Use of Estimates and Assumptions

The preparation of financial statements, in conformity with U.S. GAAP, requires management to make estimates and assumptions that affect the reported amounts of assets and liabilities and disclosure of contingent assets and liabilities at the date of the financial statements and the reported amounts of income and loss during the reporting period. Actual results could differ materially from those estimates.

2. SUMMARY OF SIGNIFICANT ACCOUNTING POLICIES

Please refer to Note 2 “Summary of Significant Accounting Policies” of the Consolidated Financial Statements in the Company’s Amendment No. 1 to the Company’s Annual Report on Form 10-K/A for the year ended September 30, 2022 for a more detailed discussion of our significant accounting policies. There were no material changes to these significant accounting policies during the three months ended December 31, 2022.

3. RESTATEMENT OF PREVIOUSLY ISSUED FINANCIAL STATEMENTS

On May 12, 2023, the audit committee of the Board of Directors of Energy Services, after considering the recommendation of management, concluded: that (a) the Company’s previously issued audited consolidated financial statements for the fiscal years ended September 30, 2022 and 2021, included in the Company’s annual reports on Form 10-K for the fiscal years ended September 30, 2022 and 2021, and (b) the Company’s unaudited consolidated financial statements for the periods ended June 30, 2021, December 31, 2021, March 31, 2022, June 30, 2022 and December 31, 2022 as reported in the Company’s quarterly reports on Form 10-Q for those periods (together, the “Reports”) should no longer be relied upon and have been restated.

Due to the economic uncertainties created by COVID-19 and limited operating funds available, the Company applied for loans under the PPP. On April 15, 2020, the Company and its subsidiaries, C.J. Hughes, Contractors Rental, and Nitro, entered into separate PPP notes effective April 7, 2020, with its Lender in an aggregate principal amount of $13.1 million pursuant to the PPP Loans. In a special meeting held on April 27, 2020, the Board of Directors of the Company unanimously voted to return $3.3 million of the PPP Loans after discussing the financing needs of the Company and subsidiaries. That left the Company and subsidiaries with $9.8 million in PPP Loans to fund operations. During fiscal year 2021, the Company received notice that the SBA had granted forgiveness of the $9.8 million of PPP Loans and the SBA repaid the Lender in full. The forgiveness was recorded as other income for the fiscal year ended September 30, 2021.

Table of Contents

requested information regarding the ability of the Company’s affiliates to meet SBA size standards and/or PPP corporate maximum limits. The requested information was subsequently provided to the SBA through the Lender. The Company recognizes that there is a possibility that the SBA could reverse its previous determination on the forgiveness of the PPP Loans. As a result of this uncertainty, the Company restated the previously issued financial statements of the Company that were included in the Reports.


	Three Months Ended December 31, 2022
	As
	Previously
	Reported		Restated		Change
Interest expense	$	474,284	$	499,428	$	25,144
Net income		163,518		138,374		(25,144)


	Three Months Ended December 31, 2021
	As
	Previously
	Reported		Restated		Change
Interest expense	$	197,559	$	222,703	$	25,144
Net income		1,170,980		1,145,836		(25,144)


	September 30, 2022
	As
	Previously
	Reported		Restated		Change
Lines of credit and short-term borrowings	$	13,080,320	$	23,164,851	$	10,084,531
Shareholders' equity		38,325,075		28,240,544		(10,084,531)


	September 30, 2021
	As
	Previously
	Reported		Restated		Change
Lines of credit and short-term borrowings	$	5,040,250	$	15,025,023	$	9,984,773
Shareholders' equity		34,637,046		24,652,273		(9,984,773)


	December 31, 2022
	As
	Previously
	Reported		Restated		Change
Lines of credit and short-term borrowings	$	12,500,000	$	22,609,675	$	10,109,675
Shareholders' equity		38,488,593		28,378,918		(10,109,675)


	December 31, 2021
	As
	Previously
	Reported		Restated		Change
Lines of credit and short-term borrowings	$	4,500,000	$	14,509,917	$	10,009,917
Shareholders' equity		34,597,764		24,587,847		(10,009,917)

Table of Contents

4. REVENUE RECOGNITION

Our revenue is primarily derived from construction contracts that can span several quarters. We recognize revenue in accordance with Accounting Standards Codification (“ASC”) Topic 606, Revenue from Contracts with Customers (“ASC 606” or “Topic 606”) which provides for a five-step model for recognizing revenue from contracts with customers as follows:

●

Identify the contract

●

Identify performance obligations

●

Determine the transaction price

●

Allocate the transaction price

●

Recognize revenue

The accuracy of our revenue and profit recognition in a given period depends on the accuracy of our estimates of the cost to complete each project. We believe our experience allows us to create materially reliable estimates. There are a number of factors that can contribute to changes in estimates of contract cost and profitability. The most significant of these include:

●

the completeness and accuracy of the original bid;

●

costs associated with scope changes;

●

changes in costs of labor and/or materials;

●

extended overhead and other costs due to owner, weather and other delays;

●

subcontractor performance issues;

●

changes in productivity expectations;

●

site conditions that differ from those assumed in the original bid;

●

changes from original design on design-build projects;

●

the availability and skill level of workers in the geographic location of the project;

●

a change in the availability and proximity of equipment and materials;

●

our ability to fully and promptly recover on affirmative claims and back charges for additional contract costs; and

●

the customer’s ability to properly administer the contract.

The foregoing factors, as well as the stage of completion of contracts in process and the mix of contracts at different margins may cause fluctuations in gross profit from period to period. Significant changes in cost estimates, particularly in our larger, more complex projects, could have a significant effect on our profitability.

Our contract assets include cost and estimated earnings in excess of billings that represent amounts earned and reimbursable under contracts, including claim recovery estimates, but have a conditional right for billing and payment such as achievement of milestones or completion of the project. With the exception of customer affirmative claims, generally, such unbilled amounts will become billable according to the contract terms and generally will be billed and collected over the next three months. Settlement with the customer of outstanding affirmative claims is dependent on the claims resolution process and could extend beyond one year. Based on our historical experience, we generally consider the collection risk related to billable amounts to be low. When events or conditions indicate that it is probable that the amounts outstanding become unbillable, the transaction price and associated contract asset is reduced.

Our contract liabilities consist of provisions for losses and billings in excess of costs and estimated earnings. Provisions for losses, if incurred, are recognized in the consolidated statements of income at the uncompleted performance obligation level for the amount of total estimated losses in the period that evidence indicates that the estimated total cost of a performance obligation exceeds its estimated total revenue. Billings in excess of costs and estimated earnings are billings to customers on contracts in advance of work performed, including advance payments negotiated as a contract condition. Generally, unearned project-related costs will be earned over the next twelve months.

Table of Contents

5. DISAGGREGATION OF REVENUE

The Company disaggregates revenue based on the following lines of service: (1) Gas & Water Distribution, (2) Gas & Petroleum Transmission, and (3) Electrical, Mechanical, & General services and construction. Our contract types are: Lump Sum, Unit Price, Cost Plus and Time and Materials (“T&M”). The following tables present our disaggregated revenue for the three months ended December 31, 2022 and 2021:


	Three Months Ended December 31, 2022
					Electrical,
	Gas & Water		Gas & Petroleum		Mechanical,		Total revenue
	Distribution		Transmission		and General		from contracts
Lump sum contracts	$	—	$	—	$	17,186,157	$	17,186,157
Unit price contracts		12,389,558		16,840,150		1,537,438		30,767,146
Cost plus and T&M contracts		—		—		12,089,282		12,089,282
Total revenue from contracts	$	12,389,558	$	16,840,150	$	30,812,877	$	60,042,585

Earned over time	$	4,878,647	$	16,840,150	$	29,890,148	$	51,608,945
Earned at point in time		7,510,911		—		922,729		8,433,640
Total revenue from contracts	$	12,389,558	$	16,840,150	$	30,812,877	$	60,042,585


	Three Months Ended December 31, 2021
					Electrical,
	Gas &Water		Gas & Petroleum		Mechanical,		Total revenue
	Distribution		Transmission		and General		from contracts
Lump sum contracts	$	—	$	—	$	10,939,201	$	10,939,201
Unit price contracts		11,962,034		11,238,517		—		23,200,551
Cost plus and T&M contracts		—		—		8,519,373		8,519,373
Total revenue from contracts	$	11,962,034	$	11,238,517	$	19,458,574	$	42,659,125

Earned over time	$	7,919,922	$	11,238,517	$	18,819,986	$	37,978,425
Earned at point in time		4,042,112		—		638,588		4,680,700
Total revenue from contracts	$	11,962,034	$	11,238,517	$	19,458,574	$	42,659,125

6. CONTRACT BALANCES

The Company’s accounts receivable consists of amounts that have been billed to customers and collateral is generally not required. Most of the Company’s contracts have monthly billing terms; however, billing terms for some are based on project completion. Payment terms are generally within 30 to 45 days after invoices have been issued. The Company attempts to negotiate two-week billing terms and 15-day payment terms on larger projects. The timing of billings to customers may generate contract assets or contract liabilities.

During the three months ended December 31, 2022, we recognized revenue of $4.5 million that was included in the contract liability balance at September 30, 2022.

Accounts receivable-trade, net of allowance for doubtful accounts, contract assets and contract liabilities consisted of the following:


	December 31, 2022		September 30, 2022		Change

Accounts receivable-trade, net of allowance for doubtful accounts	$	35,301,520	$	38,454,913	$	(3,153,393)

Contract assets
Cost and estimated earnings in excess of billings	$	14,397,681	$	16,109,593	$	(1,711,912)

Contract liabilities
Billings in excess of cost and estimated earnings	$	8,611,883	$	6,027,578	$	2,584,305

Table of Contents

7. PERFORMANCE OBLIGATIONS

For the three months ended December 31, 2022, there was no revenue recognized as a result of changes in contract transaction price related to performance obligations that were satisfied prior to September 30, 2022. Changes in contract transaction price can result from items such as executed or estimated change orders, and unresolved contract modifications and claims.

At December 31, 2022, the Company had $155.9 million in remaining unsatisfied performance obligations, in which revenue is expected to be recognized over the next twelve months.

8. UNCOMPLETED CONTRACTS

Costs, estimated earnings, and billings on uncompleted contracts as of December 31, 2022, and September 30, 2022, are summarized as follows:


	December 31, 2022		September 30, 2022
Costs incurred on contracts in progress	$	110,656,030	$	192,957,145
Estimated earnings, net of estimated losses		16,806,651		28,150,060
		127,462,681		221,107,205
Less billings to date		121,676,883		211,025,190
	$	5,785,798	$	10,082,015

Costs and estimated earnings in excess of billed on uncompleted contracts	$	14,397,681	$	16,109,593

Less billings in excess of costs and estimated earnings on uncompleted contracts		8,611,883		6,027,578
	$	5,785,798	$	10,082,015

Backlog at December 31, 2022, and September 30, 2022, was $206.9 million and $142.3 million, respectively.

9. FAIR VALUE MEASUREMENTS

The fair value measurement guidance of the Financial Accounting Standards Board (“FASB”) ASC defines fair value, establishes a framework for measuring fair value in accordance with accounting principles generally accepted in the United States of America (“U.S. GAAP”) and specifies disclosures about fair value measurements.

Under the FASB’s authoritative guidance on fair value measurements, fair value is the price that would be received to sell an asset or paid to transfer a liability in an orderly transaction between market participants at the measurement date. The fair value measurement guidance of the FASB ASC establishes a three-level hierarchy for fair value measurements based upon the transparency of inputs to the valuation of an asset or liability as of the measurement date. The three levels are defined as follows:

Level 1 — Quoted prices for identical assets and liabilities traded in active exchange markets, such as the New York Stock Exchange.

Level 2 — Observable inputs other than Level 1 including quoted prices for similar assets or liabilities, quoted prices in less active markets, or other observable inputs that can be corroborated by observable market data. Level 2 also includes derivative contracts whose value is determined using a pricing model with observable market inputs or can be derived principally from or corroborated by observable market data.

Level 3 — Unobservable inputs supported by little or no market activity for financial instruments whose value is determined using pricing models, discounted cash flow methodologies, or similar techniques, as well as instruments for which the determination of fair value requires significant management judgment or estimation; also includes observable inputs for nonbinding single dealer quotes not corroborated by observable market data.

A financial instrument’s categorization within the valuation hierarchy is based upon the lowest level of input that is significant to the fair value measurement.

Table of Contents

The carrying amount for borrowings under the Company’s revolving credit facility approximates fair value because of the variable market interest rate charged to the Company for these borrowings. The fair value of the Company’s long term fixed-rate debt was estimated using a discounted cash flow analysis and a yield rate that was estimated based on the borrowing rates currently available to the Company for bank loans with similar terms and maturities. The fair value of the aggregate principal amount of the Company’s fixed-rate debt of $26.2 million, as restated, at December 31, 2022 was $24.8 million, as restated. The fair value of the aggregate principal amount of the Company’s fixed-rate debt of $25.1 million, as restated, at September 30, 2022 was $24.3 million, as restated.

All other current assets and liabilities are carried at a net realizable value which approximates fair value because of their short duration to maturity.

10. EARNINGS PER SHARE

The amounts used to compute the earnings per share for the three months ended December 31, 2022 and 2021 are summarized below.


	As Restated		As Restated
	Three Months Ended		Three Months Ended
	December 31,		December 31,
	2022		2021
Net income	$	138,374	$	1,145,836

Weighted average shares outstanding-basic		16,667,185		16,247,898

Weighted average shares-diluted		16,667,185		16,247,898

Earnings per share-basic	$	0.01	$	0.07

Earnings per share-diluted	$	0.01	$	0.07

11. INCOME TAXES

The components of income taxes are as follows:


	Three Months Ended		Three Months Ended
	December 31, 2022		December 31, 2021
Federal
Current	$	266,966	$	671,808
Deferred		(329,064)		(286,268)
Total		(62,098)		385,540

State
Current		75,299		189,485
Deferred		(92,813)		(80,742)
Total		(17,514)		108,743

Total income tax (benefit) expense	$	(79,612)	$	494,283

The effective income tax rate for the three months ended December 31, 2022, was (135.5)%, as restated, as compared to 30.1%, as restated, for the same period in 2021. Effective income tax rates are estimates and may vary from period to period due to changes in the amount of taxable income and non-deductible expenses.

Major items that can affect the effective tax rate include amortization of goodwill and non-deductible amounts for per diem expenses.

Table of Contents

The income tax effects of temporary differences giving rise to the deferred tax assets and liabilities are as follows:


	December 31,		September 30,
	2022		2022
Deferred tax liabilities
Property and equipment	$	7,155,494	$	7,686,064
Other		530,806		7,632
Total deferred tax liabilities	$	7,686,300	$	7,693,696

Deferred income tax assets
Other	$	913,479	$	404,093
Net operating loss carryforward		2,739,620		2,834,524
Total deferred tax assets	$	3,653,099	$	3,238,617

Total net deferred tax liabilities	$	4,033,201	$	4,455,079

Deferred income taxes arise from temporary differences between the tax basis of assets and liabilities and their reported amounts in the consolidated financial statements, which will result in taxable or deductible amounts in the future. A valuation allowance is established when necessary to reduce deferred tax assets to the amount expected to be realized. At December 31, 2022, the Company expects all net operating loss carryforwards to be realized in the near future.

The Company does not believe that it has any unrecognized tax benefits included in its consolidated financial statements that require recognition. The Company has not had any settlements in the current period with taxing authorities, nor has it recognized tax benefits as a result of a lapse of the applicable statute of limitations. The Company recognizes interest and penalties accrued related to unrecognized tax benefits, if applicable, in general and administrative expenses.

The Company and all subsidiaries file a consolidated federal and various state income tax returns on a fiscal year basis. With few exceptions, the Company is no longer subject to U.S. federal, state, or local income tax examinations for years ended prior to September 30, 2018.

12. SHORT-TERM AND LONG-TERM DEBT

Operating Line of Credit

On July 13, 2022, the Company received a one-year extension on its $15.0 million operating line of credit effective June 28, 2022. The interest rate on the line of credit is the “Wall Street Journal” Prime Rate (the index) with a floor of 4.99%. The interest rate at December 31, 2022, was 7.75%. The interest rate at September 30, 2022, was 5.5%.

The line of credit has a $12.5 million component and a $2.5 million component with additional borrowing requirements. Based on the borrowing base calculation, the Company borrowed all $12.5 million available on the line of credit as of December 31, 2022 and September 30, 2022. The Company did not meet the requirements to borrow any from the $2.5 million component.

On January 19, 2023, the Company received an amendment to the agreement which increased the line of credit to $30.0 million. The maturity date remains June 28, 2023, with a variable interest rate equal to the “Wall Street Journal” Prime Rate with a floor of 4.5%.

The modified financial covenants for the quarter ended December 31, 2022, and all subsequent quarters, are below:

●

Minimum tangible net worth of $28.0 million,

●

Minimum traditional debt service coverage of 1.50x on a rolling twelve- month basis,

●

Minimum current ratio of 1.20x,

●

Maximum debt to tangible net worth ratio (“TNW”) of 2.75x,

●

Each ratio and covenant shall be determined, tested, and measured as of each calendar quarter beginning December 31, 2022,

●

The Company shall maintain a ratio of Maximum Senior Funded Debt (“SFD”) to Earnings before Interest, Taxes, Depreciation and Amortization (“EBDITA”) equal to or less than 3.5:1. SFD shall mean any funded debt or lease of the

Table of Contents

Company, other than subordinated debt. The covenant shall be tested quarterly, as of the end of each fiscal quarter, with EBITDA based on the preceding four quarters.

The Company was in compliance with all covenants at December 31, 2022, and the Company projects to meet all covenant requirements for the next twelve months.

Insurance Premiums Financed

The Company also finances insurance policy premiums on a short-term basis through a financing company. These insurance policies include workers’ compensation, general liability, automobile, umbrella, and equipment policies. The Company makes a down payment in January and finances the remaining premium amount over eleven monthly payments. At December 31, 2022 and September 30, 2022, respectively, the remaining balance of the insurance premiums was $0 and $580,000.

Paycheck Protection Program Loans

Table of Contents

A summary of short-term and long-term debt as of December 31, 2022, and September 30, 2022, is as follows:


	As restated		As restated
	December 31,		September 30,
	2022		2022
Line of credit payable to bank, monthly interest at 7.75%, final payment due by June 28, 2023, guaranteed by certain directors of the Company.	$	12,500,000	$	12,500,000

Paycheck Protection Program loans from Small Business Administration, including 1.0% simple interest, initially forgiven in the fiscal year ended September 30, 2021. Final forgiveness decision has not been determined.		10,109,675		10,084,531

Notes payable to finance companies, due in monthly installments totaling $32,000 at December 31, 2022 and $60,000 at September 30, 2022, including interest ranging from 0.00% to 6.03%, final payments due January 2023 through August 2026, secured by equipment.		776,551		889,165

Note payable to finance company for insurance premiums financed, due in monthly installments totaling $282,000 in FY 2022 and $272,000 in FY 2021, including interest rate at 3.50%, final payment due November 2022.		—		580,320

Notes payable to bank, due in monthly installments totaling $7,848, including interest at 4.82%, final payment due November 2034 secured by building and property.		854,087		867,383

Notes payable to bank, due in monthly installments totaling $12,464, including interest at 8.75%, final payment due November 2025 secured by building and property, guaranteed by certain directors of the Company.		374,201		412,917

Notes payable to bank, due in monthly installments totaling $59,932, including fixed interest at 6.0%, final payment due October 2027 secured by receivables and equipment, guaranteed by certain directors of the Company.		3,011,436		—

Notes payable to David Bolton and Daniel Bolton, due in annual installments totaling $500,000, including fixed interest at 3.25%, final payment due December 31, 2026, unsecured.		1,637,500		2,380,000

Notes payable to bank, due in monthly installments totaling $68,073, including interest at 8.75%, beginning February 2022 with final payment due September 2026, secured by equipment, guaranteed by certain directors of the Company.		2,391,154		2,549,281

Term notes payable to United Bank, Tri-State Paving acquisition, due in monthly installments of $140,000, including fixed interest at 4.50%, final payment due by June 1, 2027, secured by receivables and equipment, guaranteed by certain directors of the Company.		6,666,246		6,982,097

Notes payable to Corns Enterprises, due in annual installments totaling $250,000, including fixed interest at 3.50%, final payment due April 29, 2026, unsecured.		946,935		943,836



Total debt	$	41,629,486	$	40,718,951

Less current maturities		27,184,735		27,224,867

Total long-term debt	$	14,444,751	$	13,494,084

Table of Contents

13. GOODWILL AND INTANGIBLE ASSETS

The Company follows the guidance of ASC Topic 350, Intangibles-Goodwill and Other, which requires a company to record an impairment charge based on the excess of a reporting unit’s carrying amount of goodwill over its fair value. Under the current guidance, companies can first choose to assess any impairment based on qualitative factors (Step 0). If a company fails this test or decides to bypass this step, it must proceed with a quantitative assessment of goodwill impairment. The Company did not have a goodwill impairment at December 31, 2022 or September 30, 2022.

A table of the Company’s goodwill is below:


	December 31,		September 30,
	2022		2022
Beginning balance	$	4,087,554	$	1,814,317
Acquired		—		2,273,237
Ending balance	$	4,087,554	$	4,087,554

A table of the Company’s intangible assets subject to amortization at December 31, 2022, and September 30, 2022 is below:


				Accumulated		Accumulated		Amortization and
	Remaining Life at			Amortization and		Amortization and		Impairment Three		Net Book
	December 31,			Impairment at		Impairment at		Months Ended		Value at
Intangible assets:	2022	Original Cost		December 31, 2022		September 30, 2022		December 31, 2022		December 31, 2022
West Virginia Pipeline:
Customer Relationships	96 months	$	2,209,724	$	441,935	$	386,693	$	55,242	$	1,767,789
Tradename	96 months		263,584		52,731		46,136		6,595		210,853
Non-competes	0 months		83,203		83,203		72,806		10,397		—
Revolt Energy:
Employment agreement/non-compete	16 months		100,000		81,946		77,779		4,167		18,054
Tri-State Paving:
Customer Relationships	112 months		1,649,159	$	108,061		66,781	$	41,280		1,541,098
Tradename	112 months		203,213		13,450		8,368		5,082		189,763
Non-competes	4 months		39,960		26,607		16,590		10,017		13,353
Total intangible assets		$	4,548,843	$	807,933	$	675,153	$	132,780	$	3,740,910

The amortization on identifiable intangible assets for the three months ended December 31, 2022 and 2021 was $133,000 and $119,000, respectively.

Amortization expense associated with the identifiable intangible assets is expected to be as follows:


	Amortization Expense
January 2023 to December 2023	$	462,590
January 2024 to December 2024		433,955
January 2025 to December 2025		432,569
January 2026 to December 2026		432,569
January 2027 to December 2027		432,569
After		1,546,657
Total	$	3,740,910

14. LEASE OBLIGATIONS

Table of Contents

The Company has two lease agreements for construction equipment with a combined amount of $160,000. The leases have a term of twenty-two months with a stated interest rate of 0%, combined monthly installment payments of $6,645 and are cancellable at any time without penalty. The Company has the right to purchase the equipment at the expiration of the leases by applying the two-month deposit paid. The related assets and finance lease obligations associated with these lease agreements are included in the consolidated balance sheets within property, plant and equipment and long-term debt.

The Company has two right-of-use operating leases acquired on April 29, 2022, as part of the Tri-State Paving, LLC transaction. The first operating lease, for the Hurricane, WV facility, had a net present value of $236,000 at April 29, 2022, and a carrying value of $186,000 at December 31, 2022. The second operating lease, for the Chattanooga, Tennessee facility, had a net present value of $144,000 at April 29, 2022, and a carrying value of $103,000 at December 31, 2022. The 4.5% interest rate on the operating leases is based on the Company’s incremental borrowing rate at inception.

The Company has a right-of-use operating lease with Enterprise Fleet Management, Inc. acquired on August 11, 2022, as part of the Ryan Environmental acquisition. This lease agreement was initially for 31 vehicles to be used by Ryan Construction; however, the Company plans to add vehicles as it finds necessary. This lease had a net present value of $1.2 million at inception, and carrying value of $1.1 million at December 31, 2022. The 4.5% interest rate on the operating lease is based on the Company’s incremental borrowing rate at inception.

The Company has a right-of-use operating lease with RICA Developers, LLC acquired on August 12, 2022, as part of the Ryan Environmental acquisition. This lease, for the Bridgeport, WV facility, had a net present value of $140,000 at inception and a carrying value of $83,000 at December 31, 2022. The 4.5% interest rate on the operating lease is based on the Company’s incremental borrowing rate at inception.

Schedules related to the Company’s operating leases at December 31, 2022 can be found below:


		Remaining liability
	Years left	December 31, 2022		September 30, 2022		Lease end	Fiscal year end
Operating lease 1	2.3	$	186,427	$	205,267	4/30/2025	2025
Operating lease 2	1.4		103,472		119,032	5/31/2024	2024
Operating lease 3	3.7		1,098,727		1,166,498	8/10/2026	2027
Operating lease 4	0.7		82,992		113,480	8/11/2023	2023
		$	1,471,618	$	1,604,277

Weighted average remaining term			3.2 years


Operating Lease Maturity Schedule
January 2023-December 2023	$	559,911
January 2024-December 2024		448,309
January 2025-December 2025		352,397
January 2026-December 2026		216,265
		1,576,882
Less amounts representing interest		(105,264)
Present value of operating lease liabilities	$	1,471,618

Table of Contents


	Three months ended
	December 31, 2022
Operating Lease Expense
Amortization
Operating lease 1	$	18,841
Operating lease 2		15,559
Operating lease 3		68,528
Operating lease 4		29,612
Total amortization		132,540
Interest
Operating lease 1		2,160
Operating lease 2		1,219
Operating lease 3		12,570
Operating lease 4		1,162
Total interest		17,111
Total amortization and interest	$	149,651

The Company rents equipment for use on construction projects with rental agreements being week to week or month to month. Rental expense can vary by reporting period due to equipment requirements on construction projects and the availability of Company owned equipment. Rental expense, which is included in cost of goods sold on the consolidated statements of income, was $2.7 million and $1.9 million, respectively, for the three months ended December 31, 2022 and 2021.

15. SUBSEQUENT EVENTS

On January 18, 2023, the Company’s Board of Directors approved a special cash dividend of $0.05 per common share payable on February 15, 2023 to shareholders of record as of January 31, 2023.

On January 19, 2023, the Company received an amendment to increase its line of credit from $15.0 million to $30.0 million. The maturity date remains June 28, 2023, with a variable interest rate equal to the “Wall Street Journal” Prime Rate with a floor of 4.5%.

Management has evaluated all subsequent events for accounting and disclosure. There have been no other material events during the period, other than noted above, that would either impact the results reflected in the report or the Company’s results going forward.

Table of Contents

ITEM 2. Management’s Discussion and Analysis of Financial Condition and Results of Operations

You should read the following discussion of the financial condition and results of operations of Energy Services in conjunction with the “Financial Statements” appearing in this report as well as the historical financial statements and related notes contained elsewhere herein. Among other things, those historical consolidated financial statements include more detailed information regarding the basis of presentation for the following information. The term “Energy Services” refers to the Company, West Virginia Pipeline, SQP, Tri-State Paving, Ryan Construction, and C.J. Hughes and C.J. Hughes’ wholly owned subsidiaries on a consolidated basis.

Restatement

The accompanying information gives effect to certain adjustments made to the previously reported financial statements for the three months ended December 31, 2022 and 2021, and as of September 30, 2022. Due to the restatement of these periods, the data set forth in the accompanying management discussion and analysis may not be comparable to discussions and data in our Original Report.

Refer to “Explanatory Note” immediately preceding Item 1 of this Amendment No.1 to the Quarterly Report on Form 10-Q/A and Note 3, “Restatement of Previously Issued Financial Statements” in the accompanying consolidated financial statements for further details related to the restatement and impact on our financial statements.

Forward Looking Statements

Within Energy Services’ consolidated financial statements and this discussion and analysis of the financial condition and results of operations, there are included statements reflecting assumptions, expectations, projections, intentions or beliefs about future events that are intended as “forward-looking statements” under the Private Securities Litigation Reform Act of 1995. You can identify these statements by the fact that they do not relate strictly to historical or current facts. They use words such as “anticipate,” “estimate,” “project,” “forecast,” “may,” “will,” “should,” “could,” “expect,” “believe,” “intend” and other words of similar meaning.

These forward-looking statements are not guarantees of future performance and involve or rely on a number of risks, uncertainties, and assumptions that are difficult to predict or beyond Energy Services’ control. Energy Services has based its forward-looking statements on management’s beliefs and assumptions based on information available to management at the time the statements are made. Actual outcomes and results may differ materially from what is expressed, implied and forecasted by forward-looking statements and any or all of Energy Services’ forward-looking statements may turn out to be wrong. The accuracy of such statements can be affected by inaccurate assumptions and by known or unknown risks and uncertainties.

All of the forward-looking statements, whether written or oral, are expressly qualified by these cautionary statements and any other cautionary statements that may accompany such forward-looking statements or that are otherwise included in this report. In addition, Energy Services does not undertake and expressly disclaims any obligation to update or revise any forward-looking statements to reflect events or circumstances after the date of this report or otherwise.

Company Overview

Table of Contents

Energy Services’ customers include many of the leading companies in the industries it serves, including:

TransCanada Corporation

NiSource, Inc.

Marathon Petroleum

Mountaineer Gas

American Electric Power

Toyota Motor Manufacturing

Bayer Chemical

Dow Chemical

Kentucky American Water

West Virginia American Water

Various state, county and municipal public service districts.

The majority of the Company’s customers are in West Virginia, Virginia, Ohio, Pennsylvania, and Kentucky. However, the Company also performs work in other states including Alabama, Michigan, Illinois, Tennessee, and Indiana.

Energy Services’ sales force consists of industry professionals with significant relevant sales experience, who utilize industry contacts and available public data to determine how to market the Company’s line of products most appropriately. The Company relies on direct contact between its sales force and customers’ engineering and contracting departments to obtain new business.

All C.J. Hughes, Nitro, and Contractors Rental construction personnel are union members of various related construction trade unions and are subject to collective bargaining agreements that expire at varying time intervals. The Company believes its relationship with its unionized workforce is good.

Table of Contents

West Virginia and Pennsylvania. The employees of RCS are non-union and are managed independently from the Company’s union subsidiaries.

The Company’s website address is www.energyservicesofamerica.com.

Seasonality: Fluctuation of Results

Our revenues and results of operations can and usually are subject to seasonal variations. These variations are the result of weather, customer spending patterns, bidding seasons and holidays. The first quarter of the calendar year is typically the slowest in terms of revenues because inclement weather conditions cause delays in production and customers usually do not plan large projects during that time. While usually better than the first quarter, the second calendar year quarter often has some inclement weather which can cause delays in production, reducing the revenues the Company receives and/or increasing the production costs. The third and fourth calendar year quarters usually are less impacted by weather and usually have the largest number of projects underway. Many projects are completed in the fourth calendar year quarter and revenues are often impacted by customers seeking to either spend their capital budget for the year or scale back projects due to capital budget overruns.

In addition to the fluctuations discussed above, the pipeline industry can be highly cyclical, reflecting variances in capital expenditures in proportion to energy price fluctuations. As a result, our volume of business may be adversely affected by where our customers are in the cycle and thereby their financial condition as to their capital needs and access to capital to finance those needs.

Three Months Ended December 31, 2022, and 2021 Overview

The following is an overview of results from operations for the three months ended December 31, 2022, and 2021:


	As Restated		As Restated
	Three Months Ended		Three Months Ended
	December 31,		December 31,
	2022		2021
Revenue	$	60,042,585	$	42,659,125

Cost of revenues		54,056,323		37,350,752

Gross profit		5,986,262		5,308,373

Selling and administrative expenses		5,316,138		3,632,595
Income from operations		670,124		1,675,778

Other income (expense)
Interest income		72		576
Other nonoperating expense		(80,663)		(153,428)
Interest expense		(499,428)		(222,703)
(Loss) gain on sale of equipment		(31,343)		339,896
		(611,362)		(35,659)

Income before income taxes		58,762		1,640,119

Income tax (benefit) expense		(79,612)		494,283

Net income		138,374		1,145,836

Weighted average shares outstanding-basic		16,667,185		16,247,898

Weighted average shares-diluted		16,667,185		16,247,898

Earnings per share-basic	$	0.01	$	0.07

Earnings per share-diluted	$	0.01	$	0.07

Table of Contents

Results of Operations for the Three Months Ended December 31, 2022, Compared to the Three Months Ended December 31, 2021

Revenues. A table comparing the Company’s revenues for the three months ended December 31, 2022, compared to the three months ended December 31, 2021, is below:


	Three Months Ended				Three Months Ended
	December 31, 2022		% of total		December 31, 2021		% of total		Change		% Change
Gas & Water Distribution	$	12,487,845	20.8	%	$	11,962,034	28.0	%		525,811	4.4	%
Gas & Petroleum Transmission		16,840,150	28.0	%		11,238,517	26.3	%		5,601,633	49.8	%
Electrical, Mechanical, and General		30,714,590	51.2	%		19,458,574	45.6	%		11,256,016	57.8	%
Total	$	60,042,585	100.0	%	$	42,659,125	100.0	%		17,383,460	40.7	%

Total revenues increased by $17.4 million to $60.0 million for the three months ended December 31, 2022, as compared to $42.7 million for the three months ended December 31, 2021. The increase was a result of increased work in all categories of business.

Gas & Water Distribution revenues totaled $12.5 million for the three months ended December 31, 2022, a $526,000 increase from $12.0 million for the three months ended December 31, 2021. The revenue increase was primarily related to paving services performed on water projects, partially offset by reduced customer spending on certain blanket contracts.

Gas & Petroleum Transmission revenues totaled $16.8 million for the three months ended December 31, 2022, a $5.6 million increase from $11.2 million for the three months ended December 31, 2021. The revenue increase was primarily related to transmission work that was awarded during the fiscal year ended September 30, 2022 and completed during the first quarter of fiscal year 2023.

Electrical, Mechanical, & General construction services revenues totaled $30.7 million for the three months ended December 31, 2022, an $11.3 million increase from $19.5 million for the three months ended December 31, 2021. The revenue increase was primarily related to an increase in mechanical and electrical services performed during the three months ended December 31, 2022, as compared to the same period in the prior year.

Cost of Revenues. A table comparing the Company’s costs of revenues for the three months ended December 31, 2022, compared to the three months ended December 31, 2021, is below:


	Three Months Ended				Three Months Ended
	December 31, 2022		% of total		December 31, 2021		% of total		Change		% Change
Gas & Water Distribution	$	10,672,273	19.7	%	$	9,339,545	25.0	%		1,332,728	14.3	%
Gas & Petroleum Transmission		14,026,448	25.9	%		9,734,489	26.1	%		4,291,959	44.1	%
Electrical, Mechanical, and General		29,061,294	53.8	%		18,106,724	48.5	%		10,954,570	60.5	%
Unallocated Shop Expenses		296,308	0.5	%		169,994	0.5	%		126,314	74.3	%
Total	$	54,056,323	100.0	%	$	37,350,752	100.0	%		16,705,571	44.7	%

Total cost of revenues increased by $16.7 million to $54.0 million for the three months ended December 31, 2022, as compared to $37.4 million for the three months ended December 31, 2021. The cost of revenues increase was a result of increased work in all categories of business.

Gas & Water Distribution cost of revenues totaled $10.7 million for the three months ended December 31, 2022, a $1.3 million increase from $9.3 million for the three months ended December 31, 2021. The cost of revenue increase was primarily related to paving services performed on water projects, partially offset by reduced customer spending on certain blanket contracts.

Gas & Petroleum Transmission cost of revenues totaled $14.0 million for the three months ended December 31, 2022, a $4.3 million increase from $9.7 million for the three months ended December 31, 2021. The cost of revenue increase was primarily related to transmission work that was awarded during the fiscal year ended September 30, 2022 and completed during the first quarter of fiscal year 2023.

Electrical, Mechanical, & General construction services cost of revenues totaled $29.0 million for the three months ended December 31, 2022, a $10.9 million increase from $18.1 million for the three months ended December 31, 2021. The cost of revenue

Table of Contents

increase was primarily related to an increase in mechanical and electrical services performed during the three months ended December 31, 2022, as compared to the same period in the prior year.

Unallocated shop expenses totaled $296,000 for the three months ended December 31, 2022, a $126,000 increase from $170,000 for the three months ended December 31, 2021. The increase in unallocated shop expenses was due to decreased internal equipment charges to projects for the three months ended December 31, 2022, as compared to the same period in the prior year.

Gross Profit. A table comparing the Company’s gross profit for the three months ended December 31, 2022, compared to the three months ended December 31, 2021, is below:


	Three Months Ended					Three Months Ended
	December 31, 2022			% of total		December 31, 2021			% of total		Change		% Change
Gas & Water Distribution	$	1,815,572		30.3	%	$	2,622,489		49.4	%		(806,917)	(30.8)	%
Gas & Petroleum Transmission		2,813,702		47.0	%		1,504,028		28.3	%		1,309,674	87.1	%
Electrical, Mechanical, and General		1,653,296		27.6	%		1,351,850		25.5	%		301,446	22.3	%
Unallocated Shop Expenses		(296,308)		(4.9)	%		(169,994)		(3.2)	%		(126,314)	74.3	%
Total	$	5,986,262		100.0	%	$	5,308,373		100.0	%		677,889	12.8	%

Gross profit percentage		10.0	%				12.4	%

Total gross profit increased by $678,000 to $6.0 million for the three months ended December 31, 2022, as compared to $5.3 million for the three months ended December 31, 2021.

Gas & Water Distribution gross profit totaled $1.8 million for the three months ended December 31, 2022, a $807,000 decrease from $2.6 million for the three months ended December 31, 2021. The gross profit decrease was primarily related to less profitable water projects performed during the three months ended December 31, 2022 as compared to the same period in the prior year.

Gas & Petroleum Transmission gross profit totaled $2.8 million for the three months ended December 31, 2022, a $1.3 million increase from $1.5 million for the three months ended December 31, 2021. The gross profit increase was primarily related to transmission work that was awarded during the fiscal year ended September 30, 2022 and completed during the first quarter of fiscal year 2023.

Electrical, Mechanical, & General construction services gross profit totaled $1.7 million for the three months ended December 31, 2022, a $301,000 increase from $1.4 million for the three months ended December 31, 2021. The increase was primarily related to an increase in gross profit generated by mechanical and electrical services performed during the three months ended December 31, 2022, as compared to the same period in the prior year.

Selling and administrative expenses. Total selling and administrative expenses increased by $1.7 million to $5.3 million for the three months ended December 31, 2022, as compared to $3.6 million for the same period in the prior year. Selling and administrative expenses for operations acquired after December 31, 2021 totaled $915,000 for the three months ended December 31, 2022. The remaining increase was primarily related to additional personnel hired to secure and manage work for expected growth in fiscal year 2023.

Other nonoperating (expense) income. Other nonoperating expenses totaled $81,000 for the three months ended December 31, 2022, a decrease of $72,000 from $153,000 for the same period in the prior year.

Interest expense. Interest expense totaled $499,000 for the three months ended December 31, 2022, an increase of $276,000 from $223,000 for the same period in the prior year. The increase in interest expense was primarily due to the financing of recent acquisitions, an increase in line of credit borrowings due to increased work, and an increase in interest rates.

(Loss) Gain on sale of equipment. Loss on sale of equipment totaled ($31,000) for the three months ended December 31, 2022, a decrease of $371,000 from a gain on sale of equipment of $340,000 for the same period in the prior year. The Company sold certain underutilized or non-working pieces of equipment at auction during the three months ended December 31, 2021, with no comparable sale occurring during the three months ended December 31, 2022.

Table of Contents

Net income. Income before income taxes was $59,000 for the three months ended December 31, 2022, compared to $1.6 million for the same period in the prior year. The decrease was primarily related to the items mentioned above.

Income tax benefit for the three months ended December 31, 2022, was $80,000 compared to income tax expense of $494,000 for the same period in the prior year. The decrease in income tax expense was due to the decrease in taxable income for the three months ended December 31, 2022 as compared to the prior period.

Net income for the three months ended December 31, 2022, was $138,000, as compared to $1.1 million for the same period in the prior year.

Comparison of Financial Condition at December 31, 2022, and September 30, 2022

The Company had total assets of $107.9 million at December 31, 2022, a decrease of $4.7 million from the prior fiscal year end balance of $112.6 million.

Accounts receivable, net of allowance for doubtful accounts, totaled $35.3 million at December 31, 2022, a decrease of $3.2 million from the prior fiscal year end balance of $38.5 million. The decrease was primarily due to the timing of cash collections and project invoicing since September 30, 2022.

Contract assets totaled $14.4 million at December 31, 2022, a decrease of $1.7 million from the prior fiscal year end balance of $16.1 million. The decrease was due to a difference in the timing of project billings at December 31, 2022, compared to September 30, 2022.

Prepaid expenses and other totaled $3.2 million at December 31, 2022, a decrease of $775,000 from the prior fiscal year end balance of $3.9 million. The decrease was primarily due to expensing prepaid insurance during the three months ended December 31, 2022.

Intangible assets, net totaled $3.7 million at December 31, 2022, a decrease of $133,000 from the prior fiscal year end balance of $3.9 million. The decrease was due to the amortization of intangible assets during the three months ended December 31, 2022.

Right-of-use assets totaled $1.5 million at December 31, 2022, a decrease of $133,000 from the prior fiscal year end balance of $1.6 million. The decrease was primarily due to the amortization of operating leases during the three months ended December 31, 2022.

The Company had property, plant and equipment of $33.2 million at December 31, 2022, an increase of $551,000 from the prior fiscal year end balance of $32.7 million. The increase was due to $2.3 million in asset additions, partially offset by $1.7 million in depreciation and net equipment disposals of $124,000.

Retainage receivable totaled $5.0 million at December 31, 2022, an increase of $546,000 from the prior fiscal year end balance of $4.4 million. The increase was primarily due to more current year projects that require retainages to be withheld.

Cash and cash equivalents totaled $7.5 million at December 31, 2022, an increase of $103,000 from the prior fiscal year end balance of $7.4 million. The increase was primarily due to $3.1 million in proceeds from long-term debt and a net $1.6 million provided from operating activities, partially offset by a net $2.3 million investment in equipment, and $2.3 million in net short-term and long-term debt repayments.

Goodwill totaled $4.1 million at December 31, 2022, and September 30, 2022.

The Company had total liabilities of $79.5 million, as restated, at December 31, 2022, a decrease of $4.8 million from the prior fiscal year end balance of $84.4 million, as restated.

Accounts payable totaled $15.0 million at December 31, 2022, a decrease of $5.3 million from the prior fiscal year end balance of $20.3 million. The decrease was due to the timing of accounts payable payments as compared to September 30, 2022.

Table of Contents

Accrued expenses and other current liabilities totaled $8.8 million at December 31, 2022, a decrease of $2.5 million from the prior fiscal year end balance of $11.3 million. The decrease was due to the timing of accrued expense payments, as compared to September 30, 2022.

Lines of credit and short-term borrowings totaled $22.6 million, as restated, at December 31, 2022, a decrease of $555,000 from the prior fiscal year end balance of $23.2 million, as restated. The decrease was due to the repayment of insurance premiums financed.

Current and long-term operating lease liabilities totaled $1.5 million at December 31, 2022, a decrease of $133,000 from the prior fiscal year end balance of $1.6 million. The decrease was due to payments made during the three months ended December 31, 2022.

Deferred tax liabilities totaled $4.0 million at December 31, 2022, a decrease of $422,000 from the prior fiscal year end balance of $4.5 million. The decrease was primarily related to the reduction of the net operating loss carry forward during the three months ended December 31, 2022.

Long-term debt totaled $19.0 million at December 31, 2022, an increase of $1.5 million from the prior fiscal year end balance of $17.6 million. The increase in long-term debt was primarily due to $3.2 million in new debt agreements, partially offset by $1.7 million in debt repayments. The new long-term debt was primarily related to the financing of the equipment obtained in the Ryan Construction acquisition, which was a cash transaction at the time of the acquisition.

Contract liabilities totaled $8.6 million at December 31, 2022, an increase of $2.6 million from the prior fiscal year end balance of $6.0 million. The increase was due to a difference in the timing of project billings at December 31, 2022, as compared to September 30, 2022.

Shareholders’ equity was $28.4 million at December 31, 2022, an increase of $138,000 from the prior fiscal year end balance of $28.2 million. The increase was due to net income of $138,000 for the three months ended December 31, 2022.

Liquidity and Capital Resources

Operating Line of Credit

On July 13, 2022, the Company received a one-year extension on its $15.0 million operating line of credit effective June 28, 2022. The interest rate on the line of credit is the “Wall Street Journal” Prime Rate (the index) with a floor of 4.99%. The interest rate at December 31, 2022, was 7.5%. The interest rate at September 30, 2022, was 5.5%.

On January 19, 2023, the Company received an amendment to the agreement which increased the line of credit to $30.0 million. The maturity date remains June 28, 2023, with a variable interest rate equal to the “Wall Street Journal” Prime Rate with a floor of 4.5%.

The modified financial covenants for the quarter ended December 31, 2022, and all subsequent quarters, are below:

●

Minimum tangible net worth of $28.0 million,

●

Minimum traditional debt service coverage of 1.50x on a rolling twelve- month basis,

●

Minimum current ratio of 1.20x,

●

Maximum debt to tangible net worth ratio (“TNW”) of 2.75x,

●

Each ratio and covenant shall be determined, tested, and measured as of each calendar quarter beginning December 31, 2022,

●

Table of Contents

company, other than subordinated debt. The covenant shall be tested quarterly, as of the end of each fiscal quarter, with EBITDA based on the preceding four quarters.

The Company was in compliance with all covenants at December 31, 2022, and the Company projects to meet all covenant requirements for the next twelve months.

Insurance Premiums Financed

Paycheck Protection Program Loans

Due to the economic uncertainties created by COVID-19 and limited operating funds available, the Company applied for loans under the PPP. On April 15, 2020, the Company and its subsidiaries, C.J. Hughes, Contractors Rental and Nitro, entered into separate PPP notes effective April 7, 2020, with the Lender, in an aggregate principal amount of $13.1 million pursuant to the PPP Loans. In a special meeting held on April 27, 2020, the Board of Directors of the Company unanimously voted to return $3.3 million of the PPP Loans after discussing the financing needs of the Company and subsidiaries. That left the Company and subsidiaries with $9.8 million in PPP Loans to fund operations. During fiscal year 2021, the Company received notice that the SBA had granted forgiveness of the $9.8 million of PPP Loans and the SBA repaid the Lender in full. The forgiveness was recorded as other income for the fiscal year ended September 30, 2021.

During April 2023, management received notification from the SBA that one of the Company’s forgiveness applications related to the PPP Loans was under review. As part of the review, the SBA requested additional payroll information. Additionally, the SBA requested information regarding the ability of the Company’s affiliates to meet SBA size standards and/or PPP corporate maximum limits. The requested information was subsequently provided to the SBA through the Lender. The Company recognizes that there is a possibility that the SBA could reverse its previous determination on the forgiveness of the PPP Loans. As a result of this uncertainty, on May 12, 2023, the audit committee of the Board of Directors of Energy Services, after considering the recommendation of management, concluded: that (a) the Company’s previously issued audited consolidated financial statements for the fiscal years ended September 30, 2022 and 2021, and the related reports of its independent registered public accounting firm, Baker Tilly, included in the Company’s annual reports on Form 10-K for the fiscal years ended September 30, 2022 and 2021, and (b) the Company’s unaudited consolidated financial statements for the periods ended June 30, 2021, December 31, 2021, March 31, 2022, June 30, 2022 and December 31, 2022 as reported in the Company’s quarterly reports on Form 10-Q for those periods should no longer be relied upon and have been restated in the Amendment No. 1 to the Annual Report on Form 10-K/A and this Amendment No. 1 to the Quarterly Report on Form 10-Q/A. The Company has recorded a short-term borrowing due to the SBA inquiry for the full $9.8 million, plus accrued interest for all periods presented.

Borrowers must retain PPP documentation for at least six years after the date the loan is forgiven or paid in full, and the SBA and SBA Inspector General must be granted these files upon request. The SBA could revisit its forgiveness decision and determine that the Company does not qualify in whole or in part for loan forgiveness and demand repayment of the loans. In addition, it is unknown what type of penalties could be assessed against the Company if the SBA disagrees with the Company’s certification. Any penalties in addition to the potential repayment of the PPP Loans could negatively impact the Company’s business, financial condition and results of operations and prospects.

Long-Term Debt

On December 16, 2014, the Company’s Nitro subsidiary entered into a 20-year $1.2 million loan agreement with a bank to purchase the office building and property it had previously been leasing for $6,300 monthly. The interest rate on this loan agreement is 4.82% with monthly payments of $7,800. The interest rate on this note is subject to change from time to time based on changes in the U.S. Treasury yield, adjusted to a constant maturity of three years as published by the Federal Reserve weekly. As of December 31, 2022, the Company had made principal payments of $346,000. The loan is collateralized by the building purchased under this agreement. The note is currently held by Peoples Bank, Inc., formerly First Bank of Charleston, Inc. (West Virginia).

Table of Contents

On November 13, 2015, the Company entered into a 10-year $1.1 million loan agreement with United Bank to purchase the fabrication shop and property Nitro had previously been leasing for $12,900 each month. The variable interest rate on the loan agreement is 8.75% at December 31, 2022 with monthly payments of $12,464. As of December 31, 2022, the Company had made principal payments of $746,000. The loan is collateralized by the building and property purchased under this agreement.

On December 31, 2020, West Virginia Pipeline Acquisition Company, later renamed West Virginia Pipeline, Inc., entered into a $3.0 million sellers’ note agreement with David and Daniel Bolton for the remaining purchase price of West Virginia Pipeline, Inc. For the purchase price allocation, the $3.0 million note had a fair value of $2.85 million. As part of the $6.35 million acquisition price, the Company paid $3.5 million in cash in addition to the note. The unsecured five-year term note requires annual payments of at least $500,000 with a fixed interest rate of 3.25% on the $3.0 million sellers’ note, which equates to 5.35% on the carrying value of the note. As of December 31, 2022, the Company had made annual installment payments of $1,250,000, interest payments of $172,000 and expensed $38,000 in accreted interest.

On January 4, 2021, the Company entered into a $3.0 million Non-Revolving Note agreement with United Bank. This five-year agreement gave the Company access to a $3.0 million line of credit (“Equipment Line of Credit 2021”), specifically for the purchase of equipment, for a period of twelve months with a variable interest rate initially established at 4.25% as based on the Prime Rate as published by The Wall Street Journal. After twelve months, all borrowings against the Equipment Line of Credit 2021 were converted to a four-year term note agreement with a variable interest rate initially established at 4.25%. The loan is collateralized by the equipment purchased under this agreement. As of December 31, 2022, the Company borrowed $3.0 million against this line of credit with monthly payments of $68,150 that started in February 2022. The interest rate at December 31, 2022 was 8.75%. The Company has made principal payments of $609,000 on this note as of December 31, 2022.

On April 2, 2021, the Company entered into a $3.5 million Non-Revolving Note agreement with United Bank. This five-year agreement repaid the outstanding $3.5 million line of credit that was used for the down payment on the West Virginia Pipeline acquisition. This loan has monthly installment payments of $64,853 and has a fixed interest rate of 4.25%. The loan is collateralized by the Company’s equipment and receivables. As of December 31, 2022, the Company had made principal payments of $1.1 million.

On April 29, 2022, the Company entered into a $7.5 million Non-Revolving Note agreement with United Bank. This five-year agreement was used to finance the purchase of Tri-State Paving and has monthly payments of $129,910 with a fixed interest rate of 4.25%. The Company has made principal payments of $834,000 on this note as of December 31, 2022.

On October 10, 2022, the Company entered into a $3.1 million promissory note agreement with United Bank. This five-year agreement financed the previous cash value of equipment purchased in the Ryan Construction acquisition. This loan has monthly installment payments of $59,932 and has a fixed interest rate of 6.0%. The loan is collateralized by the Company’s equipment and receivables. As of December 31, 2022, the Company had made principal payments of $89,000.

On April 29, 2022, the Company entered into a $1.0 million promissory note agreement with Corns Enterprises, a related party, as partial consideration for the purchase of Tri-State Paving. This four-year agreement requires $250,000 principal installment payments on or before the end of each twelve (12) full calendar month period beginning April 29, 2022. Interest payments due shall be calculated on the principal balance remaining and shall be at the stated rate of 3.5% per year. The Company recorded $11,000 in accreted interest and has not made any principal payments on this note as of December 31, 2022.

The Company leases office space for SQP for $1,500 per month. The lease, signed on March 25, 2021, is for a period of two years with five one-year renewals available immediately following the end of the base term. Rental terms for the option periods shall be negotiated and agreed mutually between the parties and shall not exceed five percent increases to rent, if any. The lease is expensed monthly and not treated as a right-to-use asset as it does not have a material impact on the Company’s consolidated financial statements.

Operating Leases

Table of Contents

any time without penalty. The Company has the right to purchase the equipment at the expiration of the leases by applying the two-month deposit paid. The related assets and finance lease obligations associated with these lease agreements are included in the consolidated balance sheets within property, plant and equipment and long-term debt.

Off-Balance Sheet Arrangements

Due to the nature of our industry, we often enter into certain off-balance sheet arrangements in the ordinary course of business that result in risks not directly reflected in our balance sheets. Though for the most part not material in nature, some of these are:

Rental Agreements

The Company rents equipment for use on construction projects with rental agreements being week to week or month to month. Rental expense can vary by reporting period due to equipment requirements on construction projects and the availability of Company owned equipment. Rental expense, which is included in cost of goods sold on the consolidated statements of income, was $2.7 million and $1.9 million for the three months ended December 31, 2022, and 2021, respectively.

Letters of Credit

Certain customers or vendors may require letters of credit to secure payments that the vendors are making on our behalf or to secure payments to subcontractors and vendors on various customer projects. At December 31, 2022, the Company did not have any letters of credit outstanding.

Performance Bonds

Some customers, particularly new ones or governmental agencies require the Company to post bid bonds, performance bonds and payment bonds (collectively, performance bonds). These performance bonds are obtained through insurance carriers and guarantee to the customer that we will perform under the terms of a contract and that we will pay subcontractors and vendors. If the Company fails to perform under a contract or to pay subcontractors and vendors, the customer may demand that the insurer make payments or provide services under the bond. The Company must reimburse the insurer for any expenses or outlays it is required to make.

Currently, the Company has an agreement with a surety company to provide bonding which will suit the Company’s immediate needs. The ability to obtain bonding for future contracts is an important factor in the contracting industry with respect to the type and value of contracts that can be bid on. Depending upon the size and conditions of a particular contract, the Company may be required to post letters of credit or other collateral in favor of the insurer. Posting these letters or other collateral will reduce our borrowing capabilities. The Company does not anticipate any claims in the foreseeable future. At December 31, 2022, the Company had $79.0 million in performance bonds outstanding.

Table of Contents

Concentration of Credit Risk

In the ordinary course of business, the Company grants credit under normal payment terms, generally without collateral, to our customers, which include natural gas and oil companies, general contractors, and various commercial and industrial customers located within the United States. Consequently, the Company is subject to potential credit risk related to business and economic factors that would affect these companies. However, the Company generally has certain statutory lien rights with respect to services provided. Under certain circumstances such as foreclosure, the Company may take title to the underlying assets in lieu of cash in settlement of receivables.

Please see the tables below for customers that represent 10.0% or more of the Company’s revenue or accounts receivable, net of retention for the three months ended December 31, 2022, and 2021:


	Three Months Ended
Revenue	December 31, 2022		December 31, 2021
NiSource	14.0	%	*
TransCanada Corporation	13.6	%	17.6	%
All other	72.4	%	82.4	%
Total	100.0	%	100.0	%

* Less than 10.0% and included in “All other” if applicable


	at		at
Accounts receivable, net of retention	December 31, 2022		December 31, 2021
NiSource	19.5	%	*
WV American Water	*	%	11.0	%
Kentucky American Water	*	%	10.9	%
All other	80.5	%	78.1	%
Total	100.0	%	100.0	%

* Less than 10.0% and included in “All other” if applicable

Litigation

In February 2018, the Company filed a lawsuit against a former customer (“Defendant”) in the United States District Court for the Western District of Pennsylvania. The lawsuit is related to a dispute over work performed on a pipeline construction project. On November 21, 2022, a Judgment Order was issued, and the Company was awarded $13.1 million, of which $5.8 million was the jury award, $1.6 million was for attorney’s fees, and $5.7 million was for penalties and interest. The amounts awarded by the Judgment Order have not been recognized in the Company’s consolidated financial statements as of December 31, 2022. The Company’s attorney’s fees have been expensed as incurred. On December 16, 2022, the Defendant filed a notice of appeal with the court.

On November 12, 2021, the Company received a withdrawal liability claim from a pension plan to which the Company made pension contributions for union construction employees performing covered work in a particular jurisdiction. The Company has not performed covered work in their jurisdiction since 2011; however, the Company disagrees with the withdrawal claim and believes it is covered by an exemption under federal law. The demand called for thirty-four quarterly installment payments of $41,000 starting December 15, 2021. The Company must comply with the demand under federal pension law; however, the Company firmly believes no withdrawal liability exists. The Company is in negotiations with the pension fund to resolve the matter and all future payments have been suspended as part of the negotiation. The Company has expensed all $164,000 in payments made through December 31, 2022 and does not expect any future liabilities related to this claim.

Other than described above, at December 31, 2022, the Company was not involved in any legal proceedings other than in the ordinary course of business. The Company is a party from time to time to various lawsuits, claims and other legal proceedings that arise in the ordinary course of business. These actions typically seek, among other things, compensation for alleged personal injury, breach of contract and/or property damages, punitive damages, civil penalties or other losses, or injunctive or declaratory relief. With respect to all such lawsuits, claims, and proceedings, we record reserves when it is probable that a liability has been incurred and the amount of loss can be reasonably estimated. At December 31, 2022, the Company does not believe that any of these proceedings, separately or in aggregate, would be expected to have a material adverse effect on our financial position, results of operations or cash flows.

Table of Contents

Related Party Transactions

We intend that all transactions between us and our executive officers, directors, holders of 10% or more of the shares of any class of our common stock and affiliates thereof, will be on terms no less favorable than those terms given to unaffiliated third parties and will be approved by a majority of our independent outside directors not having any interest in the transaction.

On December 16, 2014, the Company’s Nitro subsidiary entered into a 20-year $1.2 million loan agreement with First Bank of Charleston, Inc. (West Virginia) to purchase the office building and property it had previously been leasing for $6,300 each month. The interest rate on the loan agreement is 4.82% with monthly payments of $7,800. As of December 31, 2022, the Company had paid approximately $346,000 in principal and approximately $404,000 in interest since the beginning of the loan. Mr. Douglas Reynolds, President of Energy Services, was a director and secretary of First Bank of Charleston. Mr. Samuel Kapourales, a director of Energy Services, was also a director of First Bank of Charleston. On October 15, 2018, First Bank of Charleston was merged into Premier Bank, Inc., a wholly owned subsidiary of Premier Financial Bancorp, Inc. Mr. Marshall Reynolds, Chairman of the Board of Energy Services, held the same position with Premier Financial Bancorp, Inc. Mr. Douglas Reynolds is the president and a director of Energy Services and was a director of Premier Financial Bancorp, Inc. On September 17, 2021, Peoples Bancorp, Inc., parent company of Peoples Bank, completed an acquisition of Premier Financial Bancorp, Inc. and its wholly owned subsidiaries, Premier Bank and Citizens Deposit Bank & Trust. On October 26, 2021, Mr. Douglas Reynolds was elected a director of Peoples Bancorp, Inc., and its subsidiary Peoples Bank.

On April 29, 2022, the Company entered into a $1.0 million promissory note agreement with Corns Enterprises as partial consideration for the purchase of Tri-State Paving. This four-year agreement requires $250,000 principal installment payments on or before the end of each twelve (12) full calendar month period beginning April 29, 2022. Interest payments due shall be calculated on the principal balance remaining and shall be at the stated rate of 3.5% per year.

Subsequent to the April 29, 2022 acquisition of Tri-State Paving, the Company entered into an operating lease for facilities in Hurricane, West Virginia with Corns Enterprises. This thirty-six-month lease is treated as a right-to-use asset and has payments of $7,000 per month. The total net present value at inception was $236,000 with a carrying value of $186,000 at December 31, 2022.

SQP made an equity investment of $156,000 in 1030 Quarrier Development, LLC (“Development”) in August 2022. Development is a variable interest entity (“VIE”) that is 75% owned by 1030 Quarrier Ventures, LLC (“Ventures”) and 25% owned by SQP. SQP is not the primary beneficiary of the VIE and therefore will not consolidate Development into its consolidated financial statements. Instead, SQP will apply the equity method of accounting for its investment in Development. Development, a 1% owner, and United Bank, a 99% owner, formed 1030 Quarrier Landlord, LLC (“Landlord”). Landlord decided to pursue the following development project (the “Project”): a historical building at 1030 Quarrier Street, Charleston, West Virginia as well as associated land (the “Property”) was purchased to be developed/rehabilitated into a commercial project including apartments and commercial space. Upon the completion of development, the Property will be used to generate rental income. SQP has been awarded the construction contract for the Project. United Bank provided $5.0 million in loans to fund the Project. SQP and Ventures have jointly provided an unconditional guarantee for the $5.0 million of obligations associated with the Project.

Other than mentioned above, there were no new material related party transactions entered into during the three months December 31, 2022.

Certain Energy Services subsidiaries routinely engage in transactions in the normal course of business with each other, including sharing employee benefit plan coverage, payment for insurance and other expenses on behalf of other affiliates, and other services incidental to business of each of the affiliates. All revenue and related expense transactions, as well as the related accounts payable and accounts receivable have been eliminated in consolidation.

Inflation

Most significant project materials, such as pipe or electrical wire, are provided by the Company’s customers. When possible, the Company attempts to lock in pricing with vendors and include qualifications regarding material costs increases in bids. Where allowed by contract, the Company will address fuel cost increases with customers. Significant inflation or supply chain issues could cause customers to delay or cancel planned projects; however, inflation did not have a significant effect on our results for the three months ended December 31, 2022 and 2021.

Table of Contents

Critical Accounting Estimates

The discussion and analysis of the Company’s financial condition and results of operations are based on our consolidated financial statements, which have been prepared in accordance with accounting principles generally accepted in the United States. The preparation of these consolidated financial statements requires us to make estimates and assumptions that affect the reported amounts of assets and liabilities, disclosures of contingent assets and liabilities known to exist at the date of the consolidated financial statements and reported amounts of revenues and expenses during the reporting period. We evaluate our estimates on an ongoing basis, based on historical experience and on various other assumptions that are believed to be reasonable under the circumstances. There can be no assurance that actual results will not differ from those estimates. Management believes the following accounting policies affect our more significant judgments and estimates used in the preparation of our consolidated financial statements.

Revenues

The Company recognizes revenue as performance obligations are satisfied and control of the promised good and service is transferred to the customer. For Lump Sum and Unit Price contracts, revenue is ordinarily recognized over time as control is transferred to the customers by measuring the progress toward complete satisfaction of the performance obligation(s) using an input (i.e., “cost to cost”) method. For Cost Plus and Time and Material (“T&M”) contracts, revenue is ordinarily recognized over time as control is transferred to the customers by measuring the progress toward satisfaction of the performance obligation(s) using an output method. The Company also does certain T&M service work that is generally completed in a short duration and is recognized at a point in time.

The most significant of these include:

●

the completeness and accuracy of the original bid;

●

costs associated with scope changes;

●

changes in costs of labor and/or materials;

●

extended overhead and other costs due to owner, weather and other delays;

●

subcontractor performance issues;

●

changes in productivity expectations;

●

site conditions that differ from those assumed in the original bid;

●

changes from original design on design-build projects;

●

the availability and skill level of workers in the geographic location of the project;

●

a change in the availability and proximity of equipment and materials;

●

our ability to fully and promptly recover on affirmative claims and back charges for additional contract costs; and

●

the customer’s ability to properly administer the contract.

The foregoing factors, as well as the stage of completion of contracts in process and the mix of contracts at different margins may cause fluctuations in gross profit from period to period. Significant changes in cost estimates, particularly in our larger, more complex projects could have a significant effect on our profitability.

Table of Contents

the customer of outstanding affirmative claims is dependent on the claims resolution process and could extend beyond one year. Based on our historical experience, we generally consider the collection risk related to billable amounts to be low. When events or conditions indicate that it is probable that the amounts outstanding become unbillable, the transaction price and associated contract asset is reduced.

Our contract liabilities consist of provisions for losses and billings in excess of costs and estimated earnings. Provisions for losses are recognized in the consolidated statements of income at the uncompleted performance obligation level for the amount of total estimated losses in the period that evidence indicates that the estimated total cost of a performance obligation exceeds its estimated total revenue. Billings in excess of costs and estimated earnings are billings to customers on contracts in advance of work performed, including advance payments negotiated as a contract condition. Generally, unearned project-related costs will be earned over the next twelve months.

The following table presents our costs and estimated earnings in excess of billings and billings in excess of costs and estimated earnings at December 31, 2022 and September 30, 2022:


	December 31, 2022		September 30, 2022
Costs incurred on contracts in progress	$	110,656,030	$	192,957,145
Estimated earnings, net of estimated losses		16,806,651		28,150,060
		127,462,681		221,107,205
Less billings to date		121,676,883		211,025,190
	$	5,785,798	$	10,082,015

Costs and estimated earnings in excess of billed on uncompleted contracts	$	14,397,681	$	16,109,593

Less billings in excess of costs and estimated earnings on uncompleted contracts		8,611,883		6,027,578

	$	5,785,798	$	10,082,015

Allowance for doubtful accounts

The Company provides an allowance for doubtful accounts when collection of an account is considered doubtful. Inherent in the assessment of the allowance for doubtful accounts are certain judgments and estimates relating to, among others, our customers’ access to capital, our customers’ willingness or ability to pay, general economic conditions and the ongoing relationship with the customers. While most of our customers are large well capitalized companies, should they experience material changes in their revenues and cash flows or incur other difficulties and not be able to pay the amounts owed, this could cause reduced cash flows and losses in excess of our current reserves.

Materially incorrect estimates of bad debt reserves could result in an unexpected loss in profitability for the Company. Additionally, frequently changing reserves could be an indication of risky or unreliable customers. At December 31, 2022, the management review deemed that the allowance for doubtful accounts was adequate.

Please see the allowance for doubtful accounts table below:


	December 31, 2022		September 30, 2022

Balance at beginning of year	$	70,310	$	70,310
Charged to expense		—		—
Deductions for uncollectible receivables written off, net of recoveries		(14,772)		—
Balance at end of year	$	55,538	$	70,310

Impairment of goodwill and intangible assets

Table of Contents

decides to bypass this step, it must proceed with a quantitative assessment of goodwill impairment. The Company did not have a goodwill impairment at December 31, 2022 or September 30, 2022.

Materially incorrect estimates could cause an impairment to goodwill or intangible assets and result in a loss in profitability for the Company.

A table of the Company’s intangible assets subject to amortization is below:


								Amortization and
				Accumulated		Accumulated		Impairment Nine
	Remaining Life at			Amortization and		Amortization and		Months Ended			Net Book
	December 31,			Impairment at		Impairment at		December 31,		Value at
Intangible assets:	2022	Original Cost		December 31, 2022		September 30, 2022		2022		December 31, 2022

West Virginia Pipeline:
Customer Relationships	96 months	$	2,209,724	$	441,935	$	386,693	$	55,242	$	1,767,789
Tradename	96 months		263,584		52,731		46,136		6,595		210,853
Non-competes	0 months		83,203		83,203		72,806		10,397		—

Revolt Energy:
Employment agreement/non-compete	16 months		100,000		81,946		77,779		4,167		18,054

Tri-State Paving:
Customer Relationships	112 months		1,649,159	$	108,061		66,781	$	41,280		1,541,098
Tradename	112 months		203,213		13,450		8,368		5,082		189,763
Non-competes	4 months		39,960		26,607		16,590		10,017		13,353

Total intangible assets		$	4,548,843	$	807,933	$	675,153	$	132,780	$	3,740,910

Depreciation and Amortization

The purpose of depreciation and amortization is to represent an accurate value of assets on the books. Every year, as assets are used, their values are reduced on the balance sheet and expensed on the income statement. As depreciation and amortization are a noncash expense, the amount must be estimated. Each year a certain amount of depreciation and amortization is written off and the book value of the asset is reduced.

Property and equipment are recorded at cost. Costs which extend the useful lives or increase the productivity of the assets are capitalized, while normal repairs and maintenance that do not extend the useful life or increase productivity of the asset are expensed as incurred. Property and equipment are depreciated principally on the straight-line method over the estimated useful lives of the assets: buildings 39 years; operating equipment and vehicles 5-7 years; and office equipment, furniture and fixtures 5-7 years.

Acquired intangible assets subject to amortization are amortized on a straight-line basis, which approximates the pattern in which the economic benefit of the respective intangible assets is realized, over their respective estimated useful lives. The definite-lived identifiable intangible assets recognized as part of the Company’s business combinations are recorded at their estimated fair value.

The Company’s depreciation expense for the three months ended December 31, 2022 and 2021 was $1.8 million and $1.3 million, respectively. In general, depreciation is included in “cost of revenues” on the Company’s consolidated statements of income.

The Company’s intangible amortization expense for the three months ended December 31, 2022 and 2021 was $133,000 and $119,000, respectively. In general, amortization is included in “selling and administrative expenses” on the Company’s consolidated statements of income.

Materially incorrect estimates of depreciation and amortization and/or the useful lives of assets could significantly impact the value of long-lived assets on the Company’s consolidated financial statements. A material overvaluation could result in impairment charges and reduced profitability for the Company.

Table of Contents

Income Taxes

The Company’s income tax expense and deferred tax assets and liabilities reflect management’s best estimate of current and future taxes to be paid. Significant judgments and estimates are required in the determination of the consolidated income tax expense. The Company’s provision for income taxes is computed by applying a federal rate of 21.0% and a state rate of 6.0% to taxable income or loss after consideration of non-taxable and non-deductible items.

Permanent income tax differences result in an increase or decrease to taxable income and impact the Company’s effective tax rates, which were (135.5%) and 30.1% for the three months ended December 31, 2022 and 2021, respectively. Our tax rate is affected by recurring items, such as non-deductible expenses, which we expect to be fairly consistent in the near term.

Deferred income taxes arise from temporary differences between the tax basis of assets and liabilities and their reported amounts in the consolidated financial statements, which will result in taxable or deductible amounts in the future. At December 31, 2022, the Company had a net deferred income tax liability of $4.0 million as compared to $4.5 million at September 30, 2022. The Company’s deferred income tax liabilities at December 31, 2022 totaled $7.7 million and primarily related to depreciation on property and equipment. The Company’s deferred income tax assets at December 31, 2022, totaled $3.7 million and primarily related to a NOL carryforward. The Company believes that it is more likely than not that all NOL carryforwards will be realized.

Accounting for PPP loans

The Company’s accounting for PPP loans reflects management’s best estimate of current and future amounts to be paid. The Company applies significant judgment regarding the determination of PPP loan forgiveness based on the rules established, and subsequently clarified by the SBA, including rules related to the Company’s affiliations and meeting SBA size standards.

Refer to Note 3 “Restatement of Previously Issued Financial Statements” in the accompanying consolidated financial statements for additional details.

New Accounting Pronouncements

On October 28, 2021, the Financial Accounting Standards Board (“FASB”) released Accounting Standards Update (“ASU”) 2021-08, “Business Combinations (Topic 805): Accounting for Contract Assets and Contract Liabilities from Contracts with Customers”. The amendments of this ASU require entities to apply Topic 606 to recognize and measure contract assets and contract liabilities in a business combination. The amendments improve comparability after the business combination by providing consistent recognition and measurement guidance for revenue contracts with customers acquired in a business combination and revenue contracts with customers not acquired in a business combination. The amendments are effective for public business entities for the fiscal years, including interim periods within those the fiscal years, beginning after December 15, 2022. For all other entities they are effective for the fiscal years, including interim periods within those the fiscal years, beginning after December 15, 2023. Entities should apply the amendments prospectively to business combinations that occur after the effective date. Early adoption is permitted, including in any interim period, for public business entities for periods for which financial statements have not yet been issued, and for all other entities for periods for which financial statements have not yet been made available for issuance. The Company is currently assessing the effect that ASU 2021-08 will have on their results of operations, financial position and cash flows; however, the Company does not expect a significant impact.

The FASB recently issued ASU 2021-10, “Government Assistance (Topic 832): Disclosures by Business Entities about Government Assistance”, which aims to provide increased transparency by requiring business entities to disclose information about certain types of government assistance they receive in the notes to the financial statements. Entities are required to provide the new disclosures prospectively for all transactions with a government entity that are accounted for under either a grant or a contribution accounting model and are reflected in the financial statements at the date of initially applying the new amendments, and to new transactions entered into after that date. Retrospective application of the guidance is permitted. The guidance in ASU 2021-10 is effective for financial statements of all entities for annual periods beginning after December 15, 2021, with early application permitted. ASU 2021-10 has not become effective for the Company; however, a significant impact is not expected.

Table of Contents

Subsequent Events

On January 18, 2023, the Company’s Board of Directors approved a special cash dividend of $0.05 per common share payable on February 15, 2023 to shareholders of record as of January 31, 2023.

Outlook

The following statements are based on current expectations. These statements are forward looking, and actual results may differ materially.

The Company is seeing a significant increase in bid opportunities for natural gas transmission and distribution projects along with electrical, mechanical, and general construction projects. The Company’s backlog at December 31, 2022, was $206.9 million, as compared to $101.6 million and $142.3 million at December 31, 2021, and September 30, 2022, respectively. While adding additional projects appears likely, no assurances can be given that the Company will be successful in bidding on projects that become available. Moreover, even if the Company obtains contracts, there can be no guarantee that the projects will go forward.

ITEM 3. Quantitative and Quantitative Disclosures About Market Risk

Not required for a smaller reporting company.

ITEM 4. Controls and Procedures

Evaluation of Disclosure Controls and Procedures

The Company maintains disclosure controls and procedures (as such term is defined in Rules 13a-15(e) and 15d-15(e) under the Securities Exchange Act of 1934, as amended) that are designed to ensure that information required to be disclosed by the Company in reports that it files or submits under the Exchange Act is (i) recorded, processed, summarized and reported within the time periods specified in SEC rules and forms and (ii) accumulated and communicated to the Company’s management, including its principal executive officer and principal financial officer, as appropriate to allow timely decisions regarding required disclosure.

The Company’s management carried out an evaluation, under the supervision and with the participation of the Company’s Chief Executive Officer and the Company’s Chief Financial Officer, of the effectiveness of the design and operation of the disclosure controls and procedures, as defined in Rules 13a-15(e) and 15d-15(e) under the Securities Exchange Act of 1934, as of the end of the period covered by this report. Based upon that evaluation, the Company’s Chief Executive Officer and Chief Financial Officer concluded that the Company’s disclosure controls and procedures as of December 31, 2022 were effective. However, subsequent to that assessment, management identified a material weakness in our internal controls as further described in Item 9A in our Amendment No. 1 to the Annual Report on Form 10K/A. Management re-evaluated the effectiveness of our disclosure controls and procedures as of December 31, 2022 and has concluded that our disclosure controls and procedures were not effective as of that date because of such material weakness.

Remediation Plan and Status

In response to the identified material weakness, our management, with the oversight of the Audit Committee of our Board of Directors, has dedicated significant resources, including the involvement of outside advisors, and efforts to improve our internal control over financial reporting and has taken immediate action to remediate the material weakness identified. Certain remedial actions have been completed including ongoing involvement of outside advisors to review compliance with the SBA’s rules and regulations for loan forgiveness. The Company will further enhance these controls over the remainder of fiscal year 2023.

Table of Contents

Inherent Limitations on Control Systems

Because of the inherent limitations in all control systems, no evaluation of controls can provide absolute assurance that all control issues and instances of fraud, if any, will be or have been detected. These inherent limitations include the realities that judgments in decision making can be faulty, and that breakdowns can occur because of simple error or mistake. Additionally, controls can be circumvented by the individual acts of some persons, by collusion of two or more people, or by management override of the control. The design of any system of controls is also based in part upon certain assumptions about the likelihood of future events and there can be no assurance that any design will succeed in achieving its stated goals under all potential future conditions. Over time, controls may become inadequate because of changes in conditions, or the degree of compliance with the policies or procedures may deteriorate.

Changes in Internal Control Over Financial Reporting

Except as noted above, no changes in the Company’s internal control over financial reporting occurred during the Company’s most recently completed fiscal quarter that have materially affected, or are reasonably likely to materially affect, the Company’s internal control over financial reporting.

Table of Contents

PART II

OTHER INFORMATION

ITEM 1. Legal Proceedings

Other than described above, at December 31, 2022, the Company was not involved in any legal proceedings other than in the ordinary course of business. The Company is a party from time to time to various lawsuits, claims and other legal proceedings that arise in the ordinary course of business. These actions typically seek, among other things, compensation for alleged personal injury, breach of contract and/or property damages, punitive damages, civil penalties, or other losses, or injunctive or declaratory relief. With respect to all such lawsuits, claims, and proceedings, we record reserves when it is probable that a liability has been incurred and the amount of loss can be reasonably estimated. At December 31, 2022, the Company does not believe that any of these proceedings, separately or in aggregate, would be expected to have a material adverse effect on our financial position, results of operations or cash flows.

ITEM 1A. Risk Factors

There have been no material changes in our risk factors from those previously disclosed in Item 1A of Part 1 of our Amendment No.1 to the Annual Report on Form 10-K/A for the year ended September 30, 2022.

ITEM 2. Unregistered Sales of Equity Securities and Use of Proceeds

(a)

There have been no unregistered sales of equity securities during the period covered by the report.

(b)

None.

(c)

On July 6, 2022, the Company announced a share repurchase program (“Program”), pursuant to which the Company may, from time to time, purchase shares of its common stock for an aggregate repurchase not to exceed 1,000,000 shares, which is approximately 6.0% of its outstanding common stock. The Program has no expiration date. There were no repurchases of Energy Services of America Corporation’s shares of its common stock during the three months ended December 31, 2022.

Table of Contents

ITEM 6. Exhibits


31.1		Certification of Chief Executive Officer pursuant to Rule 13a-14(a) of the Securities Exchange Act of 1934, as amended, as adopted pursuant to Section 302 of the Sarbanes-Oxley Act of 2002*

31.2		Certification of Chief Financial Officer pursuant to Rule 13a-14(a) of the Securities Exchange Act of 1934, as amended, as adopted pursuant to Section 302 of the Sarbanes-Oxley Act of 2002*

31.3		Certification of Chief Executive Officer pursuant to Rule 13a-14(a) of the Securities Exchange Act of 1934, as amended, as adopted pursuant to Section 302 of the Sarbanes-Oxley Act of 2002

31.4		Certification of Chief Financial Officer pursuant to Rule 13a-14(a) of the Securities Exchange Act of 1934, as amended, as adopted pursuant to Section 302 of the Sarbanes-Oxley Act of 2002

32.1		Certification of Chief Executive Officer and Chief Financial Officer pursuant to 18 U.S.C. Section 1350, as adopted pursuant to Section 906 of the Sarbanes-Oxley Act of 2002*

32.2		Certification of Chief Executive Officer and Chief Financial Officer pursuant to 18 U.S.C. Section 1350, as adopted pursuant to Section 906 of the Sarbanes-Oxley Act of 2002

101.INS		XBRL Instance Document

101.SCH		XBRL Taxonomy Extension Schema Document

101.CAL		XBRL Taxonomy Extension Calculation Linkbase Document

101.DEF		XBRL Taxonomy Extension Definition Linkbase Document

101.LAB		XBRL Taxonomy Extension Label Linkbase Document

101.PRE		XBRL Taxonomy Extension Presentation Linkbase Document

*	Previously included with the Company’s Quarterly Report on Form 10-Q for the period ended December 31, 2022, as filed with the Securities and Exchange Commission on February 13, 2023.

Table of Contents

SIGNATURES

Pursuant to the requirements of the Securities Exchange Act of 1934, the Company has duly caused this report to be signed on its behalf by the undersigned, thereunto duly authorized.

ENERGY SERVICES OF AMERICA CORPORATION


Date: May 31, 2023	By:	/s/ Douglas V. Reynolds
		Douglas V. Reynolds
		Chief Executive Officer

Date: May 31, 2023	By:	/s/ Charles P. Crimmel
		Charles P. Crimmel
		Chief Financial Officer

Positive
Negative
Uncertain
Constraining
Legalese
Litigous
Readability	8th grade Avg

Energy Services of America (ESOA) 10-Q/A2022 Q1 Quarterly report (amended)

Content analysis