ReneSola (SOL) 10-K2023 FY Annual report

TABLE OF CONTENTS

​

​

​

FORWARD-LOOKING STATEMENTS

This Annual Report on Form 10-K contains “forward-looking” statements within the meaning of Section 27A of the Securities Act of 1933, as amended, and Section 21E of the Securities Exchange Act of 1934, as amended, and as defined in the U.S. Private Securities Litigation Reform Act of 1995 (the “PSLRA”). All statements other than statements of historical fact included in this Form 10-K, including statements regarding the Company’s future financial condition, results of operations, plans, objectives, expectations, future performance, business operations or business prospects, are forward-looking statements. Words such as “believes,” “expects,” “anticipates,” “will,” “could,” “plans, “estimates,” “predicts,” “goals,” “should,” “will,” “could,” “would,” “may,” forecast,” “seeks,” and other similar expressions and variations of such words are intended to identify forward-looking statements and are included, along with this statement, with the intention these forward-looking statements be covered by the safe harbor provisions for forward-looking statements contained in the PSLRA. Forward-looking statements are neither historical facts, nor assurances of future performance. Instead, such statements are based only on our beliefs, expectations and assumptions regarding the future, which may not prove to be accurate, and are subject to known and unknown risks and uncertainties, many of which are outside of our control. These risks and uncertainties could cause actual events or results to differ materially from our historical experience and management’s present expectations or projections. These risks and uncertainties are discussed in this Annual Report on Form 10-K (including, but not limited to, Part I, Item 1a. Risk Factors). Any forward-looking statement speaks only as of the date on which it is made. You are cautioned not to place undue reliance on any forward-looking statements. Except as required by law, we undertake no obligation to publicly update or release any revisions to these forward-looking statements to reflect any events or circumstances after the date of this Annual Report or to reflect the occurrence of unanticipated events, whether as a result of new information, future events, or otherwise.

​

PART I

Item 1. Business

Conventions Used in This Report

The following is a list of defined terms and naming conventions used in this Annual Report on Form 10-K, unless otherwise specified.

“we,” “us,” “our company,” “our” or “Emeren” refers to Emeren Group Ltd, a British Virgin Islands company, its predecessor entities and its subsidiaries.

“ADSs” refers to our American depositary shares, each of which represents 10 shares, and “ADRs” refers to the American depositary receipts that evidence our ADSs.

“China” or “PRC” refers to the People’s Republic of China, excluding, for the purpose of this annual report on Form 10-K, Taiwan, and the special administrative regions of Hong Kong and Macau.

“CNY” or “Renminbi” refers to the legal currency of China.

“DG projects” refers to distributed generation solar power projects, including ground-mounted distributed generation projects and rooftop distributed generation projects.

“EPC” refers to engineering, procurement and construction.

“FIT” refers to feed-in tariff(s), the government guaranteed and subsidized electricity sale price at which solar power projects can sell to the national power grids, which is set by the central government.

“ground-mounted DG projects” refers to small-scale ground-mounted projects with lower grid connection voltage grade and with a substantial portion of the electricity generated to be consumed within the substation area of the grid connection points.

“ground-mounted projects” refers to solar power projects built on the ground, consisting of ground-mounted DG projects and utility-scale projects.

“GW” refers to gigawatt and “GWh” refers to gigawatt hours.

“IPP” refers to Independent Power Producer, a producer of electrical energy (power plant) that is not a public utility but which makes electricity available for sale to utilities or the general public.

“kWh” refers to kilowatt-hour.

“MW” refers to megawatts.

“NTP” refers to notice to proceed.

“PPA” refers to a power purchase agreement.

“PV” refers to photovoltaic.

“rooftop DG projects” refers to distributed generation solar power projects built on roof tops.

“RTB” refers to ready to build.

“shares” refers to shares of Emeren Group Ltd with no par value.

“SPV” refers to special purpose vehicle.

“utility-scale projects” refers to ground-mounted projects that are not ground-mounted DG projects.

“$,” “dollars” and “U.S. dollars” refer to the legal currency of the United States.

All discrepancies in any table between the amounts identified as total amounts and the sum of the amounts listed therein are due to rounding.

Overview

Emeren is a solar project developer, owner and operator with a pipeline of projects and IPP assets totaling over 3 GW, as well as a storage pipeline of over 10 GWh across Europe, North America, and Asia. Our strategy is to pursue high-margin project development opportunities in these markets. Emeren focuses on solar power project development, construction management and project financing services with local professional teams across multiple countries.

Prior to business restructuring in September 2017, the Company’s business was initially operated through its former subsidiary ReneSola Zhejiang Energy Co., Ltd., whose predecessor Zhejiang Fengding Construction Material Machinery Manufacturing Co., Ltd., or Fengding Construction, was established as a limited liability company in the PRC in 2003. Following a series of share transfers, Fengding Construction was renamed as ReneSola Zhejiang Energy Co., Ltd. in June 2005 and commenced the solar power business in July 2005.

Emeren Group Ltd was incorporated as a limited liability company in the British Virgin Islands on March 17, 2006. In January 2023, we rebranded from ReneSola Ltd. and our legal and commercial name changed to Emeren Group Ltd. Emeren stands for Empowering Renewables, to symbolize our substantial progress and continued dedication to growing solar and renewable energy development globally to deliver affordable and sustainable energy. The logo, which features a sun against a blue background, represents the sun’s energy, signifies our commitment to sustainability and serves as a reminder of the importance of renewable energy.

Our principal executive offices are located at 100 First Stamford Place, Suite 302, Stamford, CT 06902, U.S.A. Our registered office is located at the offices of Harneys Corporate Services Limited, Craigmuir Chambers, P.O. Box 71, Road Town, Tortola, VG1110, British Virgin Islands. Our agent for service of process in the United States is CT Corporation System, located at 111 Eighth Avenue, New York, New York 10011.

On September 30, 2022, we purchased 100% of the equity interest of Branston Solar Farm Limited (“Project Branston”) from P&T Global Renewable Energy Ltd. Project Branston is located in Branston, Lincoln, UK. The output of the plant is contracted under a 40-year PPA which began on the commercial operation date. The acquisition was in accordance with the Company’s overall growth strategy.

On October 11, 2022, we entered into a Shares Purchase Agreement to acquire Emeren Ltd, a United Kingdom-based utility-scale solar power and battery projects developer in Europe. The acquisition transaction was completed on October 11, 2022 through an all-cash deal with an earn-out provision.

Our Business

The Company develops and sells solar power projects or sells project SPVs (project development business); provides engineering, procurement and construction business (EPC business); and owns and operates solar power projects and sell the electricity generated by our operated solar power plants (IPP business). We conduct our IPP business, EPC business and project development business in a number of countries, including United States, Poland, Hungary, Spain, France, United Kingdom, Germany, Italy and China. Emeren is committed to streamlining solar projects with knowledge and assets for a faster implementation and an increased adoption. Our vision is to leverage solar development to realize a brighter and cleaner future.

Our Company is involved in five key areas, including:

Solar Power Project Development Business

We started our solar power project development business in 2012. We have recorded revenue from the sales of solar power projects since 2015. We have been focused on developing solar projects in different markets, including the United States, China and several European countries. See “-Our Sales and Customers.”

As a developer, we have two basic project development models:

Besides the two basic models above, we develop community solar gardens as developers and hold the community solar gardens through project SPVs. Prior to the delivery of the community solar gardens, SPVs enter into PPAs, which generally have a term of 20 years, with the power subscribers. After investors are found, we will sell the project rights, that is, the project SPV holding the community solar gardens, to investors.

The prices of our solar power projects or projects SPVs are primarily based on the cash flow such projects can generate and the rates of return. The cash flow can be affected by drivers such as electricity generation, electricity price (such as FIT or PPA), operating expenses, tax policy or a number of other reasons. Investors may compare the rate of returns generated from the solar power projects with the rates of return in the financing or investment markets.

Purchasers of our developed solar power projects normally pay the purchase price in stages. Substantially all of these purchasers may require us to provide retention money, performance bonds or bank guarantees for a certain period of time to secure the quality and performance of our developed solar power projects. During the covered period of time, if any significant defects or efficiency problem arises from sold solar power projects, it may cause the retention money to be deducted or forfeited.

The solar power project development business continues to be our important strategy for the foreseeable future.

IPP Business

We started our IPP business in 2013 by owning and operating solar power projects and selling electricity generated by these solar power projects. We have built our business as an IPP to develop and operate DG projects in well-developed regions for high PPA/FIT users.

We primarily conduct our IPP business, comprised of the solar power projects that we have developed, through our wholly and partially owned subsidiaries, where we can sell electricity in gross metering or net metering. Since 2016, we have been building an in-house O&M team in China to operate and maintain our entire owned and operated IPP portfolio in China.

In China, NEA and NDRC published the Notice on the Pilot of Distributed Generation Traded in Markets (file 2017-1901) to establish electricity trading market for DG projects which are similar to virtual net metering and US community solar gardens, allowing the IPP one of following:

Under gross metering, except for grid parity/low pilot projects in areas with ample resources, good conditions and high market consumption, each solar project approved by China’s National Development and Reform Commission, or the NDRC, is eligible to receive an attractive fixed FIT which was determined by NDRC at the time when the project was filed for 20 years in principle and we expect our solar power projects to be long-term contracted assets. Therefore, except for grid parity/low pilot projects, we can sell all electricity generated by our gross metering projects to the State Grid and receive a total amount of FIT amount, which comprises an agreed electricity sales price from the State Grid and the subsidies from the government, for 20 years. Net metering is important to achieve grid parity. We develop and operate net metering DG projects in well-developed regions in China. Under net metering, we sell a majority of the electricity to non-State Grid power purchasers at an agreed negotiated electricity sales price, which is usually at a market discount rate of the public retail rate, and then sell the remaining unpurchased electricity to the State Grid at a price based on the local desulphurized coal benchmark. Aside from the electricity sale, electricity generated (sold to non-Sate Grid power purchasers or State Grid) will receive subsidies from the government. State Grid is an enterprise which constructs and operates power grids and is a pilot state holding company approved by the State Council of China to carry out state-authorized investment. The non-State Grid power purchasers are primarily commercial and industrial users. See “-Our Solar Power Projects.” The governmental subsidies in gross metering and net metering may be different. We have focused and will continue to focus on net metering projects with high return on invested capital.

In our IPP business, power purchasers may pay us monthly, bi-monthly, quarterly or half-yearly based on the terms in the Energy Management Contract (EMCs) and PPAs. The EMCs, which, among other terms, provide the terms and pricing of the sales and include the PPAs, are long-term, generally 20 years with a possible 5-year extension.

On September 30, 2022, we acquired a 50 MWp operational solar farm (“Project Branston”) located in Branston, Lincoln, United Kingdom from P&T Global Renewable Ltd. We expanded our IPP business in Europe. Project Branston’s has been in operation since October 12, 2020 and is currently generating an annualized yield of 1,011 MWh/MWp. This fully operational solar farm provides stable cash flows and helps diversify risks from project sales. We believe the acquisition to further strengthens our market position in the Europe.

In October, 2022, we energized our first inaugural IPP project in Hungary. The project “Csomad 1-2” consists of two PV plants with total installed of 10.2 MWp, equivalent to powering approximately 4,000 households per day. The project entered the commercial operation stage in the beginning of October, 2022. The 10 MWp project in Hungary is our first self-developed and self-constructed project, which is another project to our growing IPP assets in Europe. We are committed to becoming major contributor to the renewable energy transition in Hungary.

In 2023, we started to build our own Battery Energy Storage Systems (“BESS”) projects in China to operate as an IPP based on energy arbitrage. We build and operate approximately our own 5MWh in Q4 2023. In December 2023, we acquired a 10.76 MWh energy storage power portfolio from Kunneng Smart Energy Service Group Co. Ltd. (“Kunneng Group”), which specializes in renewable energy industry, offering comprehensive solutions in solar, energy storage, power sales, and carbon asset management in China. Located in Zhejiang Province, the 10.76 MWh portfolio comprises of six energy storage power stations, operates under the Energy Management Services agreements providing benefits to the customer based on energy arbitrage. Emeren will realize its return on investments mainly from the energy arbitrage with additional revenue coming from various Virtual Power Plant “(“VPP”) scenarios. As of today, all six storage facilities are connected to VPP platform owned and operated by Huaneng Power International (0902.HK), one of the largest IPP operators in China. This is the first time Emeren is operating BESS to enter into Energy management business.

We also operate a 24MW small utility scale solar projects in North Carolina, USA.

​

As of December 31, 2023, we had more than 100 solar power plants in operation globally with an aggregate capacity of approximately 245MW and BESS 15MWh.

​

​

Owning self-consumption DG projects is an attractive business model for us, as it generates very high margin recurring revenue. However, following our long-term transformation plan to be an asset-light project developer and our new global expansion strategy, we may strategically dispose of our China DG assets depending on the market situation.

Engineering, Procurement and Construction Business

Our Engineering, Procurement and Construction Business (“EPC”) includes engineering design, procurement of solar modules, balance-of-system components and other components, and construction contracting and management. We may engage our in-house EPC team or engage external experienced and qualified EPC contractors to handle and monitor the EPC process for our developed projects. Despite that, as the developer, we may procure the key components, such as solar modules and balance-of-system components.

We typically enter into short-term contracts with our suppliers and contractors on project-by-project basis or project portfolio basis based on the market prices.

Engineering

Through engineering design, we aim to reduce the risks, reduce the costs and improve the performance of our solar power projects. The engineering design process includes the site layout and the electrical design as well as assessing a variety of factors to choose an appropriate technology, including the modules and inverters. In additional to relying on our in-house EPC team, we may engage independent third-party EPC contractors to conduct and monitor this process.

Procurement

We procure solar modules and other key components for our developed solar power projects primarily by entering into short-term contracts to purchase at market prices. Suppliers of our solar modules and key components are primarily our related parties and third-party suppliers and contractors. Our purchasing decisions may take into consideration technical specifications (including size, type and power output), bid price, warranty and insurance programs, spectral response, performance in low light, nominal power tolerance levels, degradation rate, technical support and the reputation of the supplier. We generally require warranties for defects in materials or workmanship for the components and a warranty for module capacity under normal testing conditions. Our in-house EPC team or external EPC contractors work in areas such as logistics, installation, construction and supervision. We maintain an updated list of qualified and reliable suppliers and third-party contractors with a proven track record with which we have established relationships. We choose our third-party suppliers and contractors through a bidding or quotation request process or through our affiliates or other cooperative arrangements with various manufacturers and contractors. The relevant departments of our local offices organize and collect bids and quotations, communicate with potential suppliers and contractors and coordinate with our local development teams to meet the local technical and legal requirements.

Construction

We engage third-party contractors for construction. We employ a number of measures to manage and monitor the performance of such contractors in terms of both quality and delivery time and to ensure compliance with the applicable safety and other requirements. For example, we generally have on-site supervisors and hold regular on-site meetings with the third-party contractors to monitor their work to ensure that projects progress according to schedule and adhere to quality standards. We also conduct periodic inspections to examine project implementation and quality standards compared to our project planning and prepare periodic reports for review and approval by the relevant departments in our corporate headquarters. If we identify any quality or progress issues which are attributable to the work of the third-party contractors, we will have further follow-up discussions with the third-party contractors and monitor their rectification work.

We also require our third-party contractors for construction and installation to comply with applicable laws and regulations regarding work safety as well as our own production safety rules and policies. We examine and keep records of the production-related safety documentation and insurance policies of our third-party contractors. All production-related tools and equipment used by our third-party contractors must be compliant with and certified by applicable regulatory standards. Under our third-party contracting agreements, we are generally entitled to compensation if the third-party contractors fail to meet the prescribed requirements and deadlines under their contracting agreements. In general, our contractors require us to pay all of the contract price upon completion of the solar power projects and we require the contractor to provide a performance bond, which is usually for a period of one year to two years, in respect of the warranty obligations.

Commissioning and Warranties

When the EPC contractor notifies the regional solar power project team of on-grid operation, the regional solar power project team thoroughly tests each aspect of the solar power project. Commissioning tests generally include a detailed visual inspection of all significant aspects of the plant, an open circuit voltage test and short circuit current test prior to grid connection, and a direct-current test after connecting to the power grid. These tests are conducted in order to ensure that the plant is structurally and electrically safe and is sufficiently robust to operate as designed for the specified project lifetime. We have not experienced any material delays in construction or unsatisfactory workmanship with respect to our solar power projects. Following the commissioning, the solar power projects, which are intended for sale, will be handed over to the purchasers.

In addition to the warranties provided by the manufacturers of modules, balance-of-system components and other key components, EPC contractors also typically provide a limited warranty against defects in workmanship, engineering design, and installation services under normal use and service conditions for a period of time following the energizing of a section of a solar power plant or upon substantial completion of the entire solar power plant. In resolving claims under the workmanship, design and installation warranties, the new owner has the option of remedying the defect to the warranted level through repair, refurbishment, or replacement.

Operations and Maintenance Business

Since 2016, we have been building our Operations and Maintenance (“O&M”) team to operate and maintain all of our owned and operated IPP portfolios. We utilize customized software to monitor the performance and security of our solar power projects on a real-time basis. We maintain our solar power projects to maximize the utilization rate, rate of power generation and system life of our solar power projects.

In addition to the O&M services provided by our in-house O&M team, we also engaged third-party contractors to operate and maintain substantially all of our solar power projects overseas. We are responsible for the maintenance of those projects and perform overall maintenance obligations. We subcontract certain specific O&M tasks such as security and repair to third-party contractors who are on-call to deliver such services on demand. We generally require warranties for defects in materials or components and warranties for module capacity under normal testing conditions.

Global Solar Project Development Services Business

We also provide third party renewable project development service business. In 2023, We announced our development services business with Matrix Renewables (“Matrix”) to develop Battery Energy Storage Systems (“BESS”) in Italy. This transaction demonstrates the Company’s remarkable capability to fulfill commitments outlined in the proprietary Development Service Agreement (DSA). Within just six months, Emeren has achieved a significant milestone, delivering around 1 GW in development, approaching its 1.5 GW BESS portfolio target. This achievement represents the execution capability within the frame of the partnership with Matrix, reinforcing Emeren’s position as a leading entity in the battery storage market.

Our Solar Power Projects

Since 2019, we have built our business as a project developer and have selectively owned high quality projects. We have focused on small-scale DG projects and community solar gardens with individual project size of 5 MW-25 MW. Our competitive advantages lie in small-scale projects with high PPA/FIT price in diversified jurisdictions which we believe are of attractive return and will be the trend for the development of the industry. Geographically, we are currently taking a new global expansion roadmap and strategically focusing on the promising markets in the United States and Europe.

​

​

​

Projects for Sale

As of December 31, 2023, we completed an accumulated 1.0 GW of solar power projects and have successfully monetized about a total of 130 MW of solar projects during 2023. The sales primarily included 53.6 MW of utility solar projects in Hungary and 58 MW of community solar projects in the Poland, sales of 29 MW project in China, connected to the grid 21 MW IPP projects in China. As of December 31, 2023, we had 3.1 GW within our mid-late-stage pipeline.

Project Pipeline

Our solar power projects pipeline includes early- to mid-stage projects pipeline and mid-late-stage projects pipeline. Due to different processes of developing projects in various regions, our early- to mid-stage projects pipeline refers to projects that we have internally approved to commit operational or financial resources to develop, including projects that we have conducted internal studies and are bidding for, that we are developing the financing plans, or working to obtain external approval or permits for such projects, or for which we have agreed on preliminary terms or entered into memorandums of understanding. Mid-late-stage projects mainly refer to projects that we have the legal right to develop based on definitive agreements, including the projects held by project SPVs or joint ventured project SPVs whose controlling power belongs to us, or can be purchased by us once the late stage is reached.

As of December 31, 2023, our mid-late-stage project pipeline in the United States, Poland, Hungary, France, Spain, Germany, UK, Italy and China had an aggregate capacity of approximately 3 GW.

Global Advanced Stage Pipeline:

The following table sets forth the information of our mid-late-stage pipeline as of December 31, 2023 (excluding sold, ready for sale and delivered projects):

​

Advanced Stage Pipeline

United States Pipeline:

In regards to the United States, our advanced stage projects total 1,477 MW, of which approximately 75 MW are community solar projects in Minnesota, Maine, Pennsylvania, and New York. Additionally, we have projects under development in Florida, Pennsylvania, Illinois, and California. Meanwhile, we operate 24 MW of utility scale projects in North Carolina.

​

Poland Pipeline:

Business momentum continues in Poland. As of December 31, 2023, we had 483 MW of projects in our advanced stage pipeline.

Hungary Pipeline:

In Hungary, we invest in one portfolio contains 5 projects. 2 projects are RTB, bringing total capacity to 52 MW.

​

France Pipeline:

In France, we have an advanced stage project pipeline of 92 MW, all of which are ground-mounted projects.

​

Spain Pipeline:

We have an advanced stage pipeline of 216 MW of ground-mounted projects located in various regions across Spain.

​

Germany Pipeline:

We have secured an advanced stage pipeline of 124 MW of ground-mounted projects now under development.

​

U.K. Pipeline:

We have an advanced stage pipeline of 110 MW of co-located ground-mounted / BESS projects under development.

​

Italy Pipeline:

We have secured an advanced pipeline of 471 MW of ground-mounted projects now under development.

​

China

Our new asset development pipeline of 169 MW is located in various provinces across China. All projects in China are either intended to be owned and operated by us as IPP assets, Build-Transfer, or Build-Operate-Transfer. In 2023, we sold approximately 29 MW our legacy solar assets. We intend to sell more solar projects in 2024. These include the legacy projects we built before June 30, 2019 and projects we recently built since 2021. During 2023, we significantly slowed our pace of development, because target projects could not meet our IRR goals due to high material costs and other burdens. We intend to build our asset portfolio in China but will do so in a disciplined manner that ensures we meet our profit goal.

​

Storage Pipeline

We also have a storage pipeline of about 5 GW in the U.S. and Europe at different development stages as of December 31, 2023.

​

Community Solar Gardens

As of December 31, 2023, we had community solar projects in Minnesota, Maine, Pennsylvania, Virginia and New York with the capacity of approximately 75 MW.

Utility-scale and Solar-plus-Storage Projects

In 2020, we acquired an energy storage business, including solar-plus-storage projects, from Nova Development Management. This transaction increased our development pipeline by approximately 200 MW and added an experienced solar project development team. The new team brings expertise in the development of U.S. utility scale projects, provides immediate access to battery storage, and enables us to deliver a more complete set of solution packages to our customers. Additionally, the acquisition gives us access to utility projects and development activities in several states, including Pennsylvania, California, New York, Maine, Illinois, and Arizona.

In 2021, we further expanded our development of utility scale projects in the USA into several states, including Alabama and New Mexico.

Our Sales and Customers

We selectively pursue high quality and low-risk solar power project opportunities, especially DG projects, and have been building our new solar portfolio comprised of those projects. We focus on conservative risk portfolio countries and regions where the solar power project markets are growing rapidly and expected to have sustainable growth supported by favorable government policies, including the United States, Poland, Hungary, Spain, France, Germany and the U.K. We sell our developed projects or project SPVs to purchasers, who primarily include large utility companies, other IPPs that desire to sell the electricity from the projects to local power suppliers or users, and global investors such as asset management funds, pension funds and tax equity investors. Our community solar gardens are the solutions for businesses, government entities, municipalities, schools, hospitals, residential customers, and people looking for saving money on their electricity costs.

The solar power projects for our IPP business are primarily located in China. In China, we can sell the generated electricity in gross metering to the State Grid, or in net metering to the non-State Grid power purchasers first and the remaining unpurchased electricity to the State Grid. The State Grid is an enterprise which constructs and operates power grids and is a pilot state holding company approved by the State Council of China to carry out state-authorized investment. The non-State Grid power purchasers in the net metering are primarily commercial and industrial end users. Outside of China, we sell the generated electricity primarily to the local transmission grid companies, utility companies, government entities, municipalities, community and other commercial and industrial end users.

Engineering, Procurement and Construction Business

EPC includes engineering design, procurement of solar modules, balance-of-system components and other components, and construction contracting and management. We may engage our in-house EPC team or engage external experienced and qualified EPC contractors to handle and monitor the EPC process for our developed projects. Despite that, as the developer, we may procure the key components, such as solar modules and balance-of-system components.

We typically enter into short-term contracts with our suppliers and contractors on project-by-project basis or project portfolio basis based on the market prices.

Intellectual Properties

We rely primarily on trade secrets, employee contractual protections and other contractual restrictions to establish and protect our intellectual properties and proprietary rights and maintain profitability. Nevertheless, these measures afford only limited protection and the actions we take to protect our intellectual property rights may not be adequate to provide us with meaningful protection or commercial advantage.

Quality Control

We have a risk control team to conduct comprehensive market due diligence to identify solar projects that have projected internal returns that meet our standards. We have experienced and qualified engineering teams and engage external independent experienced qualified engineering to design the projects with technical specifications that provide for the quality and performance of our solar power plants. Solar modules used in our solar power projects are from our related parties or third -party suppliers and have the certifications and meet test standards. We closely monitor and supervise construction contractors as part of the quality control process, who also typically provide warranties and performance guarantees for a period of time. Our O&M team and third party O&M service providers tests, checks and continuously monitors the quality and performance of our operating solar power projects.

Seasonality

Changes in climate, geography, weather patterns, and other phenomena in the regions where we operate may significantly affect our business. For example, solar power projects depend on the amount and intensity of sunlight, which is affected by weather and climate conditions. As a result, our IPP electricity production and amount of electricity sold and therefore our IPP revenue tend to be higher during periods or seasons when there is more irradiation. EPC construction is also affected by the weather.

Enforceability of Civil Liabilities

We are incorporated in the British Virgin Islands to take advantage of certain benefits associated with being a British Virgin Islands company, such as political and economic stability, an effective judicial system, a favorable tax system, the absence of exchange control or currency restrictions and the availability of professional and support services. However, certain disadvantages accompany incorporation in the British Virgin Islands. These disadvantages include that the British Virgin Islands has a less developed body of securities laws as compared to the United States and provides significantly less protection to investors. In addition, British Virgin Islands companies do not have standing to sue before the federal courts of the United States.

Our organizational documents do not contain provisions requiring that disputes be submitted to arbitration, including those arising under the securities laws of the United States, between us, our officers, directors and shareholders. An important part of our operations is conducted and a significant portion of our assets is located outside the United States. Some of our directors and officers are nationals or residents of jurisdictions other than the United States, and some or all of their assets are located outside the United States. As a result, it may be difficult or impossible for a shareholder to bring an original action against us or such persons in a British Virgin Islands or other foreign court in the event that a shareholder believes that his or her rights have been infringed under the U.S. federal securities laws or otherwise. It may also be difficult for a shareholder to enforce in U.S. courts judgments obtained in U.S. courts based on the civil liability provisions of the U.S. federal securities laws against us and our officers and directors, some of whom are not residents of the United States and whose assets are located outside of the United States. In addition, there is uncertainty as to whether the courts of the British Virgin Islands or other foreign jurisdictions would recognize or enforce judgments of U.S. courts against us or such persons predicated upon the civil liability provisions of the securities laws of the United States or any state. There is no statutory recognition in the British Virgin Islands of judgments obtained in the United States, although the courts of the British Virgin Islands will generally recognize and enforce a non-penal judgment of a foreign court of competent jurisdiction without retrial on the merits. It is uncertain whether British Virgin Islands or other foreign courts would be competent to hear original actions brought in the British Virgin Islands or other foreign jurisdictions against us or such persons predicated upon the securities laws of the United States or any state.

Our corporate affairs are governed by our memorandum and articles of association, or Articles, and by the BVI Business Companies Act, 2004 and common law of the British Virgin Islands. The rights of shareholders to take legal action against our directors and us, actions by minority shareholders and the fiduciary responsibilities of our directors to us under British Virgin Islands law are to a large extent governed by the common law of the British Virgin Islands. The common law of the British Virgin Islands is derived in part from comparatively limited judicial precedent in the British Virgin Islands as well as from English common law, which has persuasive, but not binding, authority on a court in the British Virgin Islands. The rights of our shareholders and the fiduciary responsibilities of our directors under British Virgin Islands law are not as clearly established as they would be under statutes or judicial precedents in the United States. In particular, the British Virgin Islands has no securities laws as compared to the United States, and provides significantly less protection to investors. In addition, British Virgin Islands companies may not have standing to initiate a shareholder derivative action before the federal courts of the United States.

As a result of all of the above, our public shareholders may have more difficulties in protecting their interests through actions against our management, directors or major shareholders than would shareholders of a corporation incorporated in a jurisdiction in the United States.

Harney Westwood & Riegels LLP, our counsel as to British Virgin Islands law, and DeHeng Law Offices, our counsel as to PRC law, have advised us that there is uncertainty as to whether the courts of the British Virgin Islands and PRC, respectively, would:

Harney Westwood & Riegels LLP has further advised us that the United States and the British Virgin Islands do not have a treaty providing for reciprocal recognition and enforcement of judgments of U.S. courts in civil and commercial matters and that a final judgment for the payment of money rendered by any federal or state court in the United States based on civil liability, whether or not predicated solely upon the U.S. federal securities laws, would not be automatically enforceable in the British Virgin Islands. We have also been advised that any final and conclusive monetary judgment for a definite sum obtained against the company in U.S. federal or state courts would be treated by the courts of the British Virgin Islands as a cause of action in itself and sued upon as a debt at common law so that no retrial of the issues would be necessary provided that:

●the U.S. federal or state court had jurisdiction in the matter and the company either submitted to such jurisdiction or was resident or carrying on business within such jurisdiction and was duly served with process;

●the judgment given by the U.S. federal or state court was not in respect of penalties, taxes, fines or similar fiscal or revenue obligations;

●the judgment was not procured by fraud;

●recognition or enforcement of the judgment in the British Virgin Islands would not be contrary to public policy; and

●the proceedings pursuant to which judgment was obtained were not contrary to natural justice.

A British Virgin Islands court may impose civil liability on us or our directors or officers in a suit brought in the courts of the British Virgin Islands against us or these persons with respect to a violation of U.S. federal securities laws, provided that the facts surrounding any violation constitute or give rise to a cause of action under British Virgin Islands law.

There is uncertainty as to whether the courts of China would (1) recognize or enforce judgments of United States courts obtained against us or such persons predicated upon the civil liability provisions of the securities laws of the United States or any state thereof, or (2) be competent to hear original actions brought in each respective jurisdiction, against us or such persons predicated upon the securities laws of the United States or any state thereof.

The recognition and enforcement of foreign judgments are provided for under the Chinese Civil Procedure Law. Chinese courts may recognize and enforce foreign judgments in accordance with the requirements of the Chinese Civil Procedure Law based either on treaties between China and the country where the judgment is made or in reciprocity between jurisdictions. China does not have any treaties or other agreements with the British Virgin Islands or the United States that provide for the reciprocal recognition and enforcement of foreign judgments. As a result, it is uncertain whether a Chinese court would enforce a judgment rendered by a court in either of these two jurisdictions.

Regulation

Regulations in the British Virgin Islands

The British Virgin Islands Economic Substance (Companies and Limited Liability Partnerships) Act 2018, as amended, came into effect on January 1, 2019. It, together with the rules published by the BVI International Tax Authority (the “ITA”) on October 9, 2019 and updated on February 10, 2020 and on February 24, 2023, set out the laws on economic substance (the “Economic Substance Laws”) and their effect on legal entities formed in the British Virgin Islands like the Company. The Company is required to consider its economic substance position on an annual basis on and from June 30, 2019 and to file annual reports in the British Virgin Islands each year disclosing whether or not it is carrying out relevant activities (within the meaning of the Economic Substance Law), and if it is, it must comply with its obligations as regards economic substance. The implication for non-compliance is, broadly, that the ITA may issue penalties and, potentially, apply to court in the British Virgin Islands to liquidate non-compliant entities.

The Company has taken and will continue to take advice from its British Virgin Islands counsel as to the steps it should take to comply with the Economic Substance Law.

Regulations in the United States

On March 31, 2021, US President Joe Biden announced to include a 10-year extension for the Investment Tax Credit (ITC) for both clean power generation and energy storage as part of a $2 trillion infrastructure investment plan. It is a proposal to extend the Investment Tax Credit and Production Tax Credit schemes for clean power generation and also to extend the credit scheme for storage. The direct-pay option for the ITC will also be maintained within the extension. Credit rates will be phased down over the 10-year period. Further measures included within the plan pertaining to clean energy are the creation of an Energy Efficiency and Clean Electricity Standard, intended to cut electricity bills and carbon emissions relating to power generation, while also increasing competition in the market.

Federal government buildings will also be mandated to procure clean power for all of their supply needs on a 24/7 basis.

Grid infrastructure upgrades have also been targeted, and a further investment tax credit will be created to incentivize the development of at least 20GW of high-voltage capacity power lines, supported by a new Grid Deployment Authority at the Department of Energy, to accelerate America’s clean energy transition.

The Inflation Reduction Act (IRA) was passed by Congress and signed into law by President Biden in August, 2022. The IRA extended and expanded tax credits available for solar generation projects, and includes over $300 billion allocated to spur investments in zero carbon power generation supply, emissions reduction technology and energy affordability programs. The IRA also establishes new incentives for low-carbon hydrogen production, Carbon Capture Utilization and Storage (CCUS), methane emissions reductions, and both transportation and building electrification.

Regulations in China

A description of the material government regulations on our business in China is summarized below:

Laws and Regulations Concerning the Renewable Energy

In February 2005, China enacted its Renewable Energy Law, which became effective on January 1, 2006 and as amended in December 2009. The Renewable Energy Law sets forth policies to encourage the development and use of solar energy and other non-fossil energy. The renewable energy law sets out the national policy to encourage and support the use of solar and other renewable energy and the use of on-grid generation. It also authorizes the relevant pricing authorities to set favorable prices for the purchase of electricity generated by solar and other renewable power generation systems. The law sets out the national policy to encourage the installation and use of solar energy water-heating systems, solar energy heating and cooling systems, photovoltaic, or PV, systems and other solar energy utilization systems. It also provides the general principles regarding financial incentives for the development of renewable energy projects. The projects, as listed in the renewable energy industry development guidance catalogue, may obtain preferential loans from financial institutions and can enjoy tax preferences.

On April 1, 2008, the PRC Energy Conservation Law came into effect (subsequently revised on October 26, 2018). Among other objectives, this law encourages the utilization and installation of solar power facilities in buildings for energy-efficiency purposes.

Laws and Regulations Concerning the Electric Power Industry

The regulatory framework of the PRC power industry consists primarily of the Electric Power Law of the PRC, which became effective on April 1, 1996 (lately revised effective on April 24, 2015 and on December 29, 2018) and the Electric Power Regulatory Ordinance, which became effective on May 1, 2005. One of the stated purposes of the Electric Power Law is to protect the legitimate interests of investors, operators and users and to ensure the safety of power operations. According to the Electric Power Law, the PRC government encourages PRC and foreign investment in the power industry. The Electric Power Regulatory Ordinance sets forth regulatory requirements for many aspects of the power industry, including, among others, the issuance of electric power business permits, the regulatory inspections of power generators and grid companies and the legal liabilities for violations of the regulatory requirements.

Obtaining the Construction Engineering Qualifications and Permit

Pursuant to the Construction Law which was promulgated by the Ministry of Construction on November 11, 1997 (effective on March 1, 1998) and amended on April 22, 2011, and April 23, 2019 and the Regulation on Administration on Qualifications of Construction Engineering which became effective on March 1, 2015 and amended on September 13, 2016 and December 13, 2018, an enterprise engaged in the design and engineering work for an electric power project must obtain a qualification certificate and must conduct its work within the strict design scope set forth in its certificate.

Pursuant to the Provisions on the Administration of Permits of Installation, Repair, and Test of Electric Power Facilities, which were promulgated by the NDRC on September 11, 2020 and became effective on October 11, 2020, any entity or individual engaged in installing, repairing or testing of electric power facilities in the PRC must obtain a permit unless otherwise exempted by the NEA. There are three categories of permits and each category is further subdivided into five levels. Each category represents a specific range of activity i.e., installation, repair and testing. Each level denotes the maximum voltage level of an electric facility that a permit holder may work with. To apply for a permit, an applicant must submit the application to the local branch of NEA. A permit holder may also apply to change either the permitted matter, which is the category or level of the permit, or the registered matter, which is the name, legal address, legal representative and other pertinent matters. A permit is valid for six years and can be renewed.

FIT and Subsidies

The Renewable Energy Law of the PRC, which was amended on December 26, 2009 and became effective on April 1, 2010, sets forth policies to encourage the development and utilization of solar power and other renewable energy. The Renewable Energy Law authorizes the relevant pricing authorities to set favorable prices for electricity generated from solar and other renewable energy sources.

On March 31, 2020, the NDRC issued the Notice on Relevant Matters Concerning the Feed-in Tariff Policy for Photovoltaic Power Generation in 2020, in which, among other things, the NDRC adopted the following measures: (i) the guide prices of new centralized photovoltaic power plant included in the scope of state financial subsidies I ~ III resource area shall respectively be CNY0.35/kWh (including tax, the same below), CNY0.4/kWh and CNY0.49/kWh. If the guide price is lower than the project location coal-fired power generation benchmark price (including desulfurization, denitrification, dust removal electricity prices), the guide price shall be subject to the local coal-fired power generation benchmark price. The feed-in tariff of new centralized photovoltaic power plants shall be determined through a competitive market approach, which shall not exceed the guide price of the resource area located; (ii) for the commercial and industrial distributed photovoltaic power generation projects included in the 2020 financial subsidy scale using the “self-generation, surplus online” model, the full power generation subsidy standard is adjusted to CNY0.05/kWh; for the commercial and industrial distributed photovoltaic power generation projects using the “full online” model, the subsidy shall be subject to the guide price of the resource area where the centralized photovoltaic power plant located. For all commercial and industrial distributed projects allocated by the energy authorities according to a unified market competition approach, the price formed by market competition shall not exceed the guide price of the resource area and the subsidy standard shall not exceed CNY0.05/kWh; and (iii) the full power generation subsidy standard of household distributed photovoltaic power generation included in the 2020 financial subsidy scale shall be adjusted to CNY0.08/kWh. The Notice was implemented as from June 1, 2020.

Mandatory Purchase of Renewable Energy

The Renewable Energy Law imposes mandatory obligations on grid enterprises to purchase the full amount of on-grid electricity generated by approved renewable energy plants whose power generation projects meet the grid connection technical standards in the areas covered by the grid enterprises’ power grids. Grid enterprises must improve the power grid construction in order to better absorb electricity generated from renewable energy.

On March 24, 2016, the NDRC issued the Measures for the Administration of Guaranteed Purchase of Full Amount of Renewable Energy, to strengthen the administration of, and provide details for, the implementation of purchase of the full amount of renewable energy by the grid enterprises.

Regulations relating to environmental protection

Enterprises conducting manufacturing activities in China are subject to provisions under the PRC environmental laws and regulations on noise, waste water, air emission and other industrial waste. The major governing environmental laws and regulations consist of the Environmental Protection Law of the PRC, which was most recently amended on April 24, 2014 and became effective on January 1, 2015, the Law of the PRC on the Prevention and Control of Water Pollution, which was most recently amended on June 27, 2017 and became effective on January 1, 2018, the Law of the PRC on the Prevention and Control of Air Pollution, which was most recently amended and became effective on October 26, 2018, the Law of the PRC on the Prevention and Control of Solid Waste Pollution, which was most recently amended on April 29, 2020 and became effective on the September 1, 2020 and the Law of the PRC on the Prevention and Control of Noise Pollution, which was promulgated on December 24, 2021 and became effective on June 5, 2022 (collectively the “Environmental Laws”). Pursuant to the Environmental Laws, PRC enterprises shall build requisite environmental treatment facilities affiliating to the manufacturing facilities, where waste air, waste water and waste solids generated can be treated properly in accordance with the relevant provisions.

Foreign Investment in Solar Power Business and Restriction on Foreign Ownership

The principal regulations governing foreign ownership of solar power businesses in the PRC are the Encouraged Foreign Investment Industries Catalog, effective as of January 1, 2023, or the Catalogue 2022, which is a replacement of the 2007, 2011, 2015, 2017, 2019 and 2020 versions of the Foreign Investment Industrial Guidance Catalogue, and the Special Administrative Measures (Negative List) for Foreign Investment Access (Edition 2021) issued by the NDRC and the PRC Ministry of Commerce. Under the Catalog 2022, the solar power industry is classified as an “encouraged foreign investment industry.” Foreign-invested enterprises in the encouraged foreign investment industry are entitled to certain preferential treatment, such as exemption from tariff on equipment imported for their operations, after obtaining approval from the PRC government authorities. Emeren PV Power was categorized in the “encouraged” industry under the Catalogue 2022.

Available Information

Emeren Group Ltd was incorporated as a limited liability company in the British Virgin Islands on March 17, 2006. Our choice of the British Virgin Islands as the jurisdiction of incorporation was motivated in part by its relatively well-developed body of corporate law, various taxes and other incentives, and its acceptance among internationally recognized securities exchanges as a jurisdiction of incorporation for companies seeking to list securities on such exchanges. As we are a limited liability company under the laws of the British Virgin Islands, the liability of our shareholders to our company is limited to (i) any amount unpaid on a share held by the shareholder and (ii) any liability to repay a distribution by our company that was not made in accordance with the laws of the British Virgin Islands.

In January 2023, we rebranded from ReneSola Ltd. and our legal and commercial name changed to Emeren Group Ltd. Emeren stands for Empowering Renewables, to symbolize our substantial progress and continued dedication to growing solar and renewable energy development globally to deliver affordable and sustainable energy. The new logo, which features a sun against a blue background, represents the sun’s energy, signifies our commitment to sustainability and serves as a reminder of the importance of renewable energy.

Our principal executive offices are located at 100 First Stamford Place, Suite 302, Stamford, CT 06902, U.S.A. Our registered office is located at the offices of Harneys Corporate Services Limited, Craigmuir Chambers, P.O. Box 71, Road Town, Tortola, VG1110, British Virgin Islands. Our agent for service of process in the United States is CT Corporation System, located at 111 Eighth Avenue, New York, New York 10011. Our website address is emeren.com. The information contained on, or that can be accessed through, our website is not a part of, and shall not be incorporated by reference into, this Annual Report. We have included our website address as an inactive textual reference only. The SEC maintains an internet site that contains reports, proxy and information statements, and other information regarding issuers, such as we, that file electronically, with the SEC at http://www.sec.gov.

​

Item 1A. Risk Factors

Summary of Risk Factors

The following risks relate principally to the industry in which we operate our business in general. Any of these risk factors could materially and adversely affect our business, financial condition or operating results and the trading price of our common shares.

Risks Related to Our Business

Risks Related to Doing Business in International Markets

Risks Related to Our ADSs and Shares

​

Risks Related to Our Business

Developing and operating solar/storage power projects exposes us to various operational risks and our result of operations may be subject to fluctuations.

In any given period, our revenue is affected by a limited number of solar power projects that are under development and sold to third parties, and therefore subject to significant fluctuations. In order to further evolve into an asset-light solar project developer with a global presence, we will continue to develop and sell solar power projects to take advantage of attractive market opportunities. As a result, for certain periods we may generate more of our revenues from the one-time sale of solar power projects.

Development of solar power projects can take many months or years to complete and may be delayed for reasons beyond our control. These projects often require us to make some up-front payments for, among other things, land/rooftop use rights and permitting in advance of commencing construction, and revenue from these projects may not be recognized for several additional months following contract signing. Any inability or significant delays in entering into sales contracts with customers after making such up-front payments could adversely affect our business and results of operations. Furthermore, we may become constrained in our ability to simultaneously fund our other investments concurrently with such projects.

Development of solar power projects also requires significant management attention to negotiate the terms of our engagement and monitor the progress of the projects which may divert management’s attention from other matters. Our revenue and liquidity may be adversely affected to the extent the market for solar power projects weakens or we are not able to successfully complete the customer acceptance testing due to technical difficulties, equipment failure, or adverse weather, and we are unable to sell our solar power projects at prices and on terms and timing that are acceptable to us. operate solar power projects and sell electricity to the local or national grid or other power purchasers such as commercial and industrial end users. As a result, we are subject to a variety of risks associated with intense market competition, changing regulations and policies, insufficient demand for solar power, technological advancements, failure of our power generation facilities and credit risks related to the power purchasers. If we cannot manage these risks, our business, financial condition and results of operations may be materially adversely affected.

Solar project development is challenging and may ultimately not be successful and miscalculations in planning a project may negatively affect our EPC prices, all of which could increase our costs, delay or cancel a project, and have a material adverse effect on our business, financial condition, results of operations and profit margins.

The development of solar projects involves numerous risks and uncertainties and requires extensive research, planning and due diligence. We may be required to incur significant amounts of capital expenditure for land/rooftop use rights, interconnection rights, preliminary engineering, permits, legal and other expenses before we can determine whether a solar power project is economically, technologically or otherwise feasible. Success in developing a solar power project is contingent upon, among other things:

Successful completion of a particular solar project may be adversely affected by numerous factors, including without limitation:

Accordingly, some of the solar power projects in our pipeline may not be completed or even proceed to construction. If a number of solar power projects are not completed, we may not benefit from the feed-in-tariffs, or FITs, our solar power projects are otherwise entitled to, and our business, financial condition and results of operations could be materially and adversely affected.

In addition, if we are unable to complete the development of a solar power project or we fail to meet any agreed upon system-level capacity or energy output guarantees or warranties or other contract terms, or our projects cause grid interference or other damage, we may be subject to significant damages, penalties and other obligations relating to the project, including obligations to repair, replace or supplement materials for the project.

Occasionally, we may enter into fixed-price EPC agreements in which we act as the general contractor for our customers in connection with the installation of their solar power systems. All essential costs are estimated at the time of entering into the EPC agreement for a particular project or project portfolio, and these costs are reflected in the overall fixed price that we charge our customers for the project. These cost estimates are preliminary and may or may not be covered by contracts between us and the subcontractors, suppliers and other parties involved in the project. In addition, we require qualified, licensed subcontractors to install most of our solar power systems. Shortages of skilled labor could significantly delay a project or otherwise increase our costs. Should miscalculations in planning a project occur, including those due to unexpected increases in commodity prices or labor costs, or delays in execution occur and we are unable to increase the EPC sales price commensurately, we may not achieve our expected margins or our results of operations may be adversely affected.

Expansion of the pipeline of our solar power project business exposes us to a number of risks and uncertainties.

As our net revenue is derived from our solar power project business, we will be increasingly exposed to the risks associated with solar power projects. Further, our future success largely depends on our ability to expand our solar power project pipeline. The risks and uncertainties associated with our solar power project business and our ability to expand our solar power project pipeline include:

If we are unable to successfully expand our solar power project business, and in particular, our solar power project pipeline, we may be unable to expand our business, maintain our competitive position, improve our profitability and generate the cash flows we have currently forecasted.

We may not be able to develop or acquire additional attractive solar power projects to grow our NTP portfolio.

Our current business strategy includes plans to further grow the solar power project portfolio for our project rights sale business, or NTP portfolio, and own and operate some of the solar power projects we develop. To develop a solar power project, we are required to enter into investment agreements, development agreements, interconnection agreements and/or other contractual agreements with the local authorities and obtain relevant permits, licenses and approvals. Whether or not we can secure an investment agreement is subject to the discretion of government bodies and utilities, and may be influenced by factors beyond our control, such as market conditions and the allocated solar power project quota in some countries, based on which the agreement can be entered into government incentive programs. Our competitors may have greater financial resources, more effective or established localized business presence or greater willingness or ability to operate with little or no operating margins for sustained periods of time. It is difficult to predict whether and when we will be awarded a new solar power project. Any increase in competition or reduction in our competitive capabilities could have a significant adverse impact on our market share and on the margins we generate from our solar power projects.

If we cannot complete an agreement on schedule, or at all, the PPA/FIT price may be reduced, our reputation may be damaged and the difficulty of winning new projects may increase. In addition, in any event the government bodies terminate an agreement with us, we will have limited recourse. Although the government bodies have historically not terminated agreements with us, there is no assurance that they would not do so in the future.

If we cannot secure the opportunities to develop new solar power projects, our business, financial position and financial conditions will be materially adversely affected.

Other difficulties executing this business strategy, particularly in new jurisdictions we may enter, include:

Our financial leverage may hamper our ability to expand and may materially affect our results of operations.

We have relied on working capital, short-term and long-term financing, including development loan financings, construction loan financings and project financings, and capital market financings to fund our capital requirements and expect to continue to do so in the future. These financings, which consist of short-term borrowings, long-term borrowings, bond and other long-term liabilities, are primarily from financial institutions and fund investors globally, as well as financing lease companies in China. During 2023, we repaid debt totaling over $12.1 million. As of December 31, 2023, we had borrowings of $36.7 million and finance lease liabilities of $3.2 million. We had a working capital of $169.5 million as of December 31, 2023 and the amount of our borrowings and financing liabilities could constrain our operational flexibility, including requiring a substantial portion of our cash flows to be set aside to service our debt obligations, increasing our exposure to interest rate fluctuations and limiting our ability to obtain additional financing. Furthermore, governments may pass measures to tighten credit. All the above may impair our ability to obtain financing on favorable terms, or at all. In addition, we may not be able to raise necessary funding on favorable terms, or at all, to refinance our debt obligations. If our cash flows and capital resources are insufficient to service our debt obligations, our business, prospects and financial conditions may be materially and adversely affected. If we fail to obtain additional sources of financing, we may not be able to continue to fund our operations or business.

As needed, we intend to obtain additional debt obligations to finance our operations and future expansion. To the extent we are successful in obtaining additional financing, we will allocate an increasing portion of our cash flows to service our debt obligations. This could impair our ability to make necessary capital expenditures, develop business opportunities or make strategic acquisitions. Our business may not generate sufficient cash flows from operations in the future to service our debt and make necessary capital expenditures, in which case we may seek additional financing, dispose of certain assets or seek to refinance some or all of our debt. In addition, these alternatives may not be implemented on satisfactory terms, if at all. In the event we are unable to meet our debt obligations when they become due or if our creditors take legal action against us for repayment upon any default, we may have to liquidate our long-term assets to repay our creditors. Such a situation would materially and adversely affect our operations and prevent us from successfully implementing our business strategy. In addition, we may have difficulty converting our long-term assets into current assets in such a situation and may suffer losses from the sale of our long-term assets and may not be able to continue our business.

We may not be able to identify suitable sites or obtain related access and use right to expand our project pipeline.

Solar power projects require solar and geological conditions that can only be found in a limited number of geographic areas.

Our solar power projects in overseas markets are primarily ground-mounted DG projects, with a few small-scale utility-scale projects and community solar gardens. Our solar power projects in China are primarily the rooftop DG projects. There is intense competition for a limited number of project sites appropriate for solar power projects. As the solar power project market continues to evolve, the number of attractive project sites available has decreased and will continue to decrease.

Even if we sign investment or development agreements, we may not be able to find and secure the use rights to suitable project sites for the relevant projects. We generally obtain land for our ground-mounted projects through land use right granting or assignment by the government, or leasing from the land owners; and obtain the access and use rights for our rooftop DG projects through leasing from the rooftop owners. Our rights to the properties used for our solar power projects may be challenged by property owners or other third parties, in case of any disputes over the ownership or lease of the properties. It is critical to guarantee and maintain our land use right on the land parcel and access and use right on the rooftop during the life cycle of solar power projects. In case the relevant lease agreement was determined null and void by the competent authorities or our land use right and access and use right on rooftops were recouped by the government, our solar power projects may be forced to cease operations and our results of operation and financial condition will be materially adversely affected.

We require flat land parcels for our small-scale solar power projects, including ground-mounted DG projects, small-scale utility projects and community solar gardens. Also, it is crucial to have a land parcel close to the grid connection point for our ground-mounted projects for interconnection to the power grid and in order to control the cost for the construction of transmission line and avoid the electricity transmission loss. However, it is increasingly difficult to secure flat land parcels close to transmission lines. Once we have identified a suitable site, our ability to obtain requisite land use rights or access and use rights to the rooftop is subject to growing competition from other solar energy producers that may have better access to local government support, financial or other resources to locate and obtain rights of such sites. Our competitors may impede our development efforts by acquiring control of all or a portion of a solar site we seek to develop. If we were unable to find or obtain use rights for suitable solar power project sites, our ability to develop new solar power projects on a timely basis might be harmed, which could have a material adverse effect on our business, financial condition and results of operations.

We strictly check the land ownership and use and access rights to avoid agricultural land, wetland or any land which requires rezoning. However, we cannot assure you that we will not acquire land with the understanding that such land may be rezoned for solar power project development in the future. Rezoning may take longer than expected or may not been possible. Any future rezoning efforts may materially and adversely impact our business and results of operation.

We may be subject to unforeseen costs, liabilities or obligations when operating and maintaining solar power projects.

We operate and maintain the solar power projects in our IPP portfolio. In addition to the operations and maintenance, or O&M, services which our in-house O&M team provides to our developed solar power projects in China, we also enter into separate contractual agreements to operate and maintain substantially all of the solar power projects operated by us outside China. Pursuant to these agreements, we generally perform scheduled and unscheduled maintenance, and provide operating and other asset management services, and we subcontract certain O&M services, including security and repair, to third-parties that may not perform their services adequately.

If we or our third-party contractors fail to properly operate and maintain the solar power projects, the solar power projects may experience decreased performance, reduced useful life or shutdowns. Through changes in our own operation or in local conditions, the costs of operating the project may increase, including costs related to labor, equipment, insurance and taxes. If they are careless or negligent, resulting in damage to third parties, we may become liable for the consequences of any resulting damage. We may also experience equipment malfunction or failure, leading to unexpected maintenance needs, unplanned outages or other operational issues. In addition, inconsistencies in the quality of solar panels, solar modules, balance-of-system components or maintenance services for our solar power projects may affect the system efficiency of our solar power projects. We may also encounter difficulties selling electricity to the power grid due to failures in infrastructure or transmission systems. To the extent that any of the foregoing affects our ability to sell electricity to the power grid, or we incur increased costs in relation to operating and maintaining solar power projects, our business, financial condition and results of operation could be materially and adversely affected.

The delay between making significant upfront investments in our solar power projects and receiving revenue could materially and adversely affect our liquidity, business and results of operations.

There are generally many months or even years between our initial significant upfront investments in developing permits to develop solar power projects we expect to own and operate and when we commence to receive revenue from the sale of electricity generated by such solar power projects after connecting on grid. Such investments include, without limitation, consulting, legal, accounting and other third-party fees, costs associated with feasibility study, payments for land rights, government permits, large transmission and PPA deposits or other payments, which may be non-refundable. Furthermore, we historically relied on our own equity contribution, bank loans, capital market financing and third-party financing to pay for costs and expenses incurred during project development, especially to third parties for solar modules, balance-of-system components and EPC and O&M services. Solar power projects typically generate revenue only after becoming commercially operational and starting to sell electricity. There may be an especially long delay from initial land and interconnection assessments to projects becoming mid-late-stage, especially when we obtain permits directly from regulators and site control rights directly from prior rights holders under our primary permit development model. Between our initial investments in the development of permits for solar power projects and their connection to the transmission grid, there may be adverse developments to such solar power projects. Furthermore, we may not be able to obtain all of the permits as anticipated, permits that were obtained may expire or become ineffective or we may not be able to obtain financing as anticipated. In addition, the timing gap between our upfront investments and actual generation of revenue, or any added delay in between due to unforeseen events, could put strains on our liquidity and resources, and materially and adversely affect our profitability and results of operations.

Our ability to transmit and sell the electricity generated from the solar power projects operated by us relies on the grid connection, dispatch agreements, PPAs and other contractual agreements.

We sell electricity generated from our operated solar power projects, mainly in China. Before developing a solar power project for our IPP business, we have to obtain the relevant local governmental grid company’s preliminary consent on our grid connection application and the final approval on the grid connection plan in order to connect our solar power projects to their power grids.

In China, we can sell the electricity in gross metering or net metering. Under gross metering, electricity is sold to The State Grid Corporation of China, or the State Grid, an enterprise which constructs and operates power grids and is a pilot state holding company approved by the State Council of China to carry out state-authorized investment. Under the net metering, we first sell the electricity to non-State Grid power purchasers and the remaining unpurchased electricity to the State Grid. Before we can supply the electricity to our power purchasers, we are required to enter into the grid connection and dispatch agreements with the grid providers and energy management contracts, or EMCs, including PPAs with the power purchasers. Grid connection and dispatch agreements generally have terms of 1 to 5 years and are, in practice, subject to renewal by the parties when original terms expire. The EMCs, which provide the terms and pricing of the sales and include the PPAs, are for 20 years and are subject to renewal by the parties when original terms expire. If we are unable to renew the agreements upon expiration, we may not be able to replace them with agreements with equivalent terms and conditions, or at all, or we may experience significant delays or costs related to securing replacements. If we are unable to agree with the grid providers on a new grid connection and dispatch agreements, the affected solar power project may temporarily or permanently cease operations, and we may not be able to operate the project beyond the initial term of the EMCs and PPAs. See also “We face a number of risks involving PPAs and project-level financing arrangements, including failure or delay in entering into PPAs, defaults by counterparties and contingent contractual terms such as price adjustment, termination, buy-out, acceleration or other clauses, all of which could materially and adversely affect our business, financial condition, results of operations and cash flows.” In addition, if, for any reason, the grid providers are unable or unwilling to fulfill their related contractual obligations or if they refuse to accept delivery of electricity delivered thereunder or otherwise terminate such agreements prior to the expiration thereof, our business, financial condition, results of operations and cash flow could be materially adversely affected.

Decreases in the FIT price, public utility price or market discount rate could harm our revenue.

Revenues generated from our IPP business are primarily from China. Under gross metering, the revenues we can receive are fixed at the FIT price which is set by the government. Under net metering, the prices we sell the electricity to the non-State Grid power purchasers are mainly at a market discount to the public utility rate. The market price of electricity can be subject to significant fluctuations and can be affected by drivers such as the cost of traditional fossil fuels used for electricity generation, the discovery of new fossil fuel sources, additional electricity generation capacity, additional electric transmission and distribution lines, technological or regulatory changes, increased energy conservation or for a number of other reasons. However, given that China largely runs a state-led economy, the FIT price may be readily lowered by the relevant Chinese authorities with little, if any, regard to market conditions. While we may resort to domestic courts and other available forums for remedies, such actions may bear no fruit and are bound to generate extra legal costs and fees. Regardless of the rationales underlying the price adjustments, any decrease in the FIT price, market discount rate or the public utility rate may negatively affect our results of operations.

EPC is subject to risks associated with fluctuations in the prices of solar modules and balance-of-system components or fluctuations in the costs of design, construction and labor.

EPC is part of the process during the solar power projects’ development and construction. We may engage our in-house EPC team or engage external experienced and qualified EPC contractors to conduct and monitor the EPC process. Despite that, it is the market practice for us, as the developer, to procure the key components, such as solar modules and balance-of-system components. Design, construction, labor and installation costs incurred by our in-house EPC team or external EPC contracts may also vary. Any increase in the prices of solar modules or balance-of-system components or fluctuations in design, construction, labor and installation costs may increase our procurement cost for the key components or costs to engage external contractors and hence may materially and adversely affect our results of operations.

The reduction, modification, delay or elimination of government subsidies and economic incentives for on-grid solar power applications may reduce the profitability of our business and materially adversely affect our business.

We believe that the near-term growth of the market for on-grid applications continues to depend on the availability and size of government subsidies and economic incentives which can be influenced by various factors, such as national subsidy policy and the local desulphurized coal benchmark electricity price. If the reduction or elimination of government subsidies and economic incentives are not implemented prudently, such reduction or elimination may adversely affect the growth of this market or result in increased price competition, either of which could cause our revenues to decline.

When upfront system costs are factored into the cost of electricity generation, the cost of solar power substantially exceeds the cost of power generated from conventional means in many markets. As a result, national and local governmental bodies in many countries have provided subsidies and economic incentives in the form of FITs, rebates, tax credits and other incentives to end-users, distributors, system integrators and manufacturers of solar power products to promote the use of solar power and to reduce dependence on other forms of energy.

However, as the solar power industry continues to develop, these government subsidies and economic incentives have been reduced and could continue to be reduced or be eliminated altogether. For example, reductions in FIT programs in Germany have continued since 2014 and the government in China has issued various policies to control FIT for on-grid solar power projects since 2014.

Although the solar power industry is currently moving towards the economies of scale necessary for solar power to become cost-effective in a non-subsidized market, any reduction, modification, delay or elimination of government subsidies and economic incentives by the Chinese government and the governments of other countries for on-grid solar power applications could result in decreased demand and pricing of our solar power projects, which could materially and adversely affect our revenues and profitability.

Our future success substantially depends on our ability to closely monitor and accurately predict market demand which exposes us to a number of risks and uncertainties.

We intend to closely match our solar power projects and electricity to the market demand for our products. Any failure to accurately predict market demand may result in our below-supply or oversupply of our solar power projects and electricity required to meet the market demand. Our ability to achieve a balance is subject to significant risks and uncertainties, including:

If we are unable to successfully respond to market demand, or if we fail to resolve any of the risks and uncertainties, we may be unable to expand our business, maintain our profitability and stay competitive. Moreover, even if we are able to manage our growth, we may be unable to secure sufficient purchase orders to maintain profitability or stay competitive within the industry, which could adversely affect our business and operations.

Concentration in a limited number of customers for the sale of our utility-scale projects may expose us to additional risks and significant fluctuations or declines in our revenues.

In our project development, we may sell our utility-scale projects only to utilities companies or grid system operators. Although most of our developed solar power projects are not utility-scale projects, concentration in a limited number of customers in this utility-scale project market may, among other impacts, limit our ability to engage other purchasers, reduce our power to negotiate the pricing terms and sales terms of our agreements and increase our reliance on payment from the governmental grid companies, which may cause fluctuations or declines in our revenues.

Limited number of purchasers of electricity generated by solar energy may expose us and our solar power projects to additional risk.

Transmission and distribution of electricity is either monopolized or highly concentrated in most jurisdictions and there are a limited number of possible purchasers for electricity generated by solar power in a given geographic location, including transmission grid operators, state and investor-owned power companies, public utility districts and cooperatives. As a result, there is a concentrated pool of potential purchasers for electricity generated by our solar power plants and projects, which may restrict our ability to negotiate favorable terms under new PPAs and could impact our ability to find new customers for the electricity generated by our generation facilities should this become necessary. Furthermore, if the financial condition of these grid companies, utilities and/or power purchasers deteriorates or government policies or regulations to which they are currently subject that compel them to source renewable energy supplies change, demand for electricity produced by our plants could be negatively impacted. In addition, provisions in our PPAs or applicable laws may provide for the curtailment of delivery of electricity for various reasons, including preventing damage to transmission systems, system emergencies, force majeure or economic reasons. Such curtailment would reduce revenues to us from PPAs. If we cannot enter into PPAs on terms favorable to us, or at all, or if the purchaser under our PPAs were to exercise its curtailment or other rights to reduce purchases or payments under such arrangements, our revenues and our decisions regarding development of additional projects in the energy segment may be adversely affected.

We operate in a highly competitive market and many of our competitors have greater resources than we do. We may not be able to compete successfully, and we may lose or be unable to gain market share.

The solar market is increasingly competitive and continually evolving, which may result in price reductions, reduced profit margins or loss of market share by us. The roll-out of attractive solar energy policies around the globe may make this industry increasingly lucrative and thus intensify the competition by attracting more interested companies. Our primary competitors include local and international developers and operators of solar power projects in those markets. Some of our competitors may have integrated with upstream solar manufacturers and may have advantages over us in terms of greater operational, financial, technical, management or other resources in particular markets or in general. They may have longer operating histories, stronger market positions, larger development capabilities, operation skills, greater resources, better brand name recognition, better access to favorable prices, more established distribution networks and larger customer bases than we do. As a result, they may be able to devote greater resources to the research, development, promotion and sale of their products or respond more quickly to evolving industry standards and changes in market conditions than we can. We only started our solar power projects business in recent years. There is no guarantee that we can compete successfully in the markets where we currently operate or the markets we plan to enter in the future.

In addition, in certain of our markets, such as China, state-owned and private companies have emerged to take advantage of the significant market opportunity created by attractive financial incentives and favorable regulatory environment provided by the governments. State-owned companies may have stronger relationships with local governments in certain regions and private companies may be more focused and experienced in developing solar power projects in the markets where we compete. Accordingly, we need to continue to be able to compete against both state-owned and private companies in these markets.

Moreover, the key barriers to enter into our industry at present consist primarily of in-depth market knowledge, skilled personnel, consistent development capacity, access to capital resources and competitive cost structure. If these barriers disappear or become more easily surmountable, new competitors may successfully enter our industry. If we fail to compete successfully, our business would suffer, and we may lose or be unable to gain market share.

We also earn revenues from generation and sales of electricity. We believe that our primary competitors in these markets are the incumbent utilities companies which supply energy to our potential customers under highly regulated rate and tariff structures. We compete with these conventional utilities primarily based on price, predictability of price, reliability of delivery and the ease with which customers can switch to electricity generated by our solar power projects.

As the solar power and renewable energy industry grows and evolves, we will also face new competitors who are not currently in the market. Our competitors may also enter into strategic alliances or form affiliates with other competitors to our detriment. Suppliers or contractors may merge with our competitors which may limit our choices of contractors and hence the flexibility of our overall project execution capabilities. There can be no assurance that our current or potential competitors will not offer solar power projects or services comparable or superior to those that we offer at the same or lower prices or adapt more quickly than we do.

We also face competition from other renewable energy companies and non-renewable power industries, including nuclear energy and fossil fuels such as coal, petroleum and natural gas. Technological innovations in these other forms of energy may reduce their costs or increase their safety. Large-scale new deposits of fossil fuel may be discovered, which could reduce their costs. Local governments may decide to strengthen their support for other renewable energy sources, such as wind, hydro, biomass, geothermal and ocean power, and reduce their support for the solar industry. The inability to compete successfully against producers of other forms of power or otherwise enter into power purchase agreements favorable to us would reduce our market share, negatively affect our ability to develop and finance our projects and negatively impact our results of operations.

We operate in a highly competitive market. Increased competition may result in price reductions, reduced profit margins and loss of market share. Our market position depends on our financing, development and operation capabilities, reputation, experience and track record. Our failure to adapt to changing market conditions and to compete successfully with existing or new competitors in the solar power industry, as well as the other renewable energy companies and non-renewable power companies, will limit our growth and will have a material adverse effect on our business and prospects.

Our project operations may be adversely affected by weather and climate conditions, pandemics, natural disasters and adverse work environments.

Solar power projects depend on the amount and intensity of sunlight, which is affected by weather and climate conditions. Any change of such conditions in the areas we operate that reduces solar radiation will adversely affect our business and results of operations. In addition, we may operate in areas that are under the threat of floods, earthquakes, landslides, mudslides, sandstorms, drought, or other inclement weather and climate conditions or natural disasters. If inclement weather or climatic conditions or natural disasters occur in areas where our solar power projects and project teams are located, project development, connectivity to the power grid and the provision of O&M services may be adversely affected. In particular, materials may not be delivered as scheduled and labor may not be available. As many of our solar power projects are located in the same region, such solar power projects may be simultaneously affected by weather and climate conditions, natural disasters, adverse work environments or a pandemic, such as the COVID - 19 pandemic.

During periods of curtailed activity, we may continue to incur operating expenses. We may bear some or all of the losses associated with such unforeseen events. Moreover, natural disasters which are beyond our control may adversely affect the economy, infrastructure and communities in the countries and regions where we conduct our business. Such conditions may have an adverse effect on our work performance, progress and efficiency or even result in personal injuries or fatalities.

Seasonal variations may influence our results of operations.

Changes in climate, geography, weather patterns, and other phenomena in the regions where we operate may significantly affect our business. For example, solar power projects depend on the amount and intensity of sunlight, which is affected by weather and climate conditions. As a result, our electricity generation and amount of electricity sold and therefore the revenue generated from our IPP business tend to be higher during periods or seasons when there is more irradiation. Seasonal variations could adversely affect our results of operations and make them more volatile and unpredictable.

Information system failures, cyber incidents or breaches in security could adversely affect us.

We rely on accounting, financial, operational, management and other information systems to conduct our operations. Our information systems are subject to damage or interruption from power outages, computer and telecommunication failures, computer viruses, security breaches, including malware and phishing, cyberattacks, natural disasters, usage errors by our employees and other related risks. Any cyber incident or attack or other disruption or failure in these information systems, or other systems or infrastructure upon which they rely, could adversely affect our ability to conduct our business and could have a material adverse effect on our business, prospects, liquidity, financial condition and results of operations. Furthermore, any failure or security breach of information systems or data could result in a violation of applicable privacy and other laws, significant legal and financial exposure, damage to our reputation or a loss of confidence in our security measures, which could harm our business and could have a material adverse effect on our business, prospects, liquidity, financial condition and results of operations. Although we have implemented systems and processes intended to secure our information systems, there can be no assurance that our efforts to maintain the security and integrity of our information systems will be effective or that future attempted security breaches or disruptions would not be successful or damaging.

We are subject to counterparty risks under our FIT price support schemes and PPAs.

As an IPP, we generate revenue from the sale of electricity primarily pursuant to FIT price support schemes or PPAs, which subject us to counterparty risks with respect to regulatory regimes. Relevant regulatory authorities may retroactively alter their FIT price support regimes in light of changing economic circumstances,

Changing industry conditions or for any number of other reasons. If the relevant government authorities, the local power grid companies or other counter parties or responsible parties do not perform their obligations under the FIT price support schemes and PPAs and we are unable to enforce our contractual rights, our results of operations and financial condition may be materially and adversely affected.

Restrictive covenants and undertakings under our project financing arrangements and loan arrangements may limit the manner in which we operate and an event of default under the loan may adversely affect our operations.

We obtain financing from financial institutions and fund investors globally, as well as financing lease companies in China. These financing arrangements contain certain restrictive covenants that limit our ability to, among other things, (i) dispose of or provide guarantees, pledges or mortgages on our operating assets in any manner that will increase risk to the lenders, (ii) repay shareholders loans or loans from our related parties, (iii) distribute dividends to shareholders, (iv) enter into other financial obligations to third parties, (v) transfer shares, (vi) make investments, and (vii) take part in any mergers or acquisitions. For more information, see “Item 5. Operating and Financial Review and Prospects—Liquidity and Capital Resources.” With our expansion into the downstream solar power projects business, we may continue to incur additional development loans, construction loans and project financing in connection with the solar power projects. Any breach by us of the various undertakings and covenants in our existing or future financing arrangements may give such lenders the right to demand immediate repayment of the outstanding loan amounts. We cannot assure you whether we will be subject to, or be able to fulfill, such undertakings in the future. Any failure to maintain any of the above covenants or undertakings could result in an acceleration of obligations under the facility agreements, which would have a material adverse effect on our business. In addition, the breach of any of the covenants and undertakings in any loan agreement may trigger the cross-default provisions in substantially all of our financing arrangements and/or the cross-acceleration provisions in some of those financing arrangements, thereby giving the lenders the right to accelerate our loan repayment obligations. As a result, we are limited in how we conduct our business and may be unable to engage in certain business activities or finance our future operations or capital needs.

Our advance payments to our suppliers expose us to the credit risk of such suppliers, which may adversely affect our financial condition and results of operations.

We typically made advance payments in connection with our procurement agreements for our solar power project business. To the extent that there is collateral and/or security attached to the advance payments, it is uncertain whether the advance payment can be repaid in full upon enforcement on such collateral or security. Any litigation arising out of disputes relating to such prepayments could subject us to potentially significant legal expenses, distract management from the day-to-day operation of our business and expose us to risks for not being able to collect damages awarded to us, all of which could materially and adversely affect our financial condition and results of operations.

We may not be able to recover such advance payments and would suffer further losses if any supplier fails to fulfill its delivery obligations under its supply contract, which would include failure to provide sufficient quantity of materials of such quality as specified in the contract. Claims by us for advance payments or other supplier obligations under the supply contracts in the future may potentially expose us to the credit risks of the suppliers and other market risks and therefore materially and adversely affect our financial condition and results of operations.

Future acquisitions, investments or alliances may have an adverse effect on our business.

If we are presented with appropriate opportunities, we may make additional investment into our solar power projects or acquire or invest in businesses or assets that are strategically important to our business or form alliances with key players in the solar power industry to further expand our business. Such acquisitions and investments could expose us to potential risks, including risks associated with the assimilation of new operations, technologies and personnel, unforeseen or hidden liabilities, the inability to generate sufficient revenue to offset the costs and expenses of acquisitions and potential loss of, or harm to, our relationships with employees, customers and suppliers as a result of the integration of new businesses. We may not be able to maintain a satisfactory relationship with our partners or handle other risks associated with future alliances, which could adversely affect our business and results of operations. Investments in new businesses may also divert our cash flow from servicing our debt and making necessary capital expenditures. In addition, we may incur impairment losses on our acquisitions and investments in equity securities.

Problems with the quality or performance of our developed solar power projects could result in increased costs, damage to our reputation and loss of revenues and market share.

In our project development business, substantially all of our purchasers may require us to provide retention money, performance bonds or bank guarantees for a certain period of time to secure the quality and performance of our developed solar power projects. During the covered period of time, if any significant defects or efficiency problem arises from sold solar power projects, it may incur additional costs to us for providing remedial measures, divert the attention of our personnel from our operations and cause the retention money to be deducted or forfeited. Similarly, if we fail to maintain the consistent quality of our other solar power projects via effective quality control, it could also cause significant damage to our market reputation, reduce our product sales and market share and adversely affect our results of operations and business.

Risks Related to Doing Business in International Markets

We conduct our business globally and are subject to global and local risks related to economic, regulatory, social and political uncertainties.

We conduct our IPP business and/or project development business in a number of countries, such as United States, Poland, Hungary, Spain, France, UK, Germany, Italy and China. Within the United States, our business footprints spread over many states and the idiosyncrasies of those states in terms of regulatory environment and legal framework may have a material impact on our local operations. Our business is therefore subject to diverse and constantly changing economic, regulatory, social and political conditions in the jurisdictions in which we operate.

Conducting business in the international markets exposes us to a number of risks globally and in each of the jurisdictions where we operate, including, without limitation:

To the extent that our business operations are affected by unexpected and adverse economic, regulatory, social and political conditions in the jurisdictions in which we have operations, we may experience project disruptions, loss of assets and personnel, and other indirect losses that could adversely affect our business, financial condition and results of operations.

We are subject to numerous laws and regulations at the national, regional and local levels of government in the areas where we do business. Any changes to these regulations and policies may present technical, regulatory and economic barriers to the purchase and use of solar projects and solar electricity, which may significantly reduce demand for our products and services or otherwise adversely affect our financial performance.

We conduct our business internationally and are subject to a variety of laws and regulations, some of which may conflict with each other and all of which are subject to change, including energy regulations, tax laws and regulations, environmental regulations, labor laws and other government requirements, approvals, permits and licenses.

In countries where we do business, the market for solar power projects and solar electricity is heavily influenced by national, state and local government regulations and policies concerning the electric utility industry, as well as policies disseminated by electric utilities. These regulations and policies often relate to electricity pricing and technical interconnection of customer-owned electricity generation, and could deter further investment in the research and development of alternative energy sources as well as customer purchases of solar power technology, which could result in a significant reduction in the potential demand for our solar power projects and solar electricity.

Changes in applicable energy laws or regulations, or in the interpretations of these laws and regulations, could result in increased compliance costs or the need for additional capital expenditures. If we fail to comply with these requirements, we could also be subject to civil or criminal liability and the imposition of fines. Further, national, regional or local regulations and policies could be changed to provide for new rate programs that undermine the economic returns for both new and existing projects by charging additional, non-negotiable fixed or demand charges or other fees or reductions in the number of projects allowed under net metering policies.

National, regional or local government energy policies, laws and regulations supporting the creation of wholesale energy markets are currently, and may continue to be, subject to challenges, modifications and restructuring proposals, which may result in limitations on the commercial strategies available to us for the sale of our power.

Regulatory changes in a jurisdiction where we are developing a project may make the continued development of the project infeasible or economically disadvantageous and any expenditure we have made to date on such project may be wholly or partially written off. Any of these changes could significantly increase the regulatory related compliance and other expenses incurred by the projects and could significantly reduce or entirely eliminate any potential revenues that can be generated by one or more of the projects or result in significant additional expenses to us, our off takers and customers, which could materially and adversely affect our business, financial condition, results of operations and cash flows.

We may also face regulatory risks imposed by various transmission providers and operators, including regional transmission operators and independent system operators, and their corresponding market rules. These regulations may contain provisions that limit access to the transmission grid or allocate scarce transmission capacity in a particular manner, which could materially and adversely affect our business, financial condition, results of operations and cash flows.

We are also subject to the Foreign Corrupt Practices Act of 1977, or the FCPA, and other anti-bribery and anti-money laundering laws in the United States and the countries in which we conduct our business. We face significant liabilities if we fail to comply with the FCPA and other anti-bribery and anti-money laundering laws. We may have direct or indirect interactions with officials and employees of government agencies or state-owned or affiliated entities. For example, in China, we enter into PPAs with local subsidiaries of the State Grid to sell our solar electricity. In other countries where we develop, acquire or sell solar projects, we need to obtain various approvals, permits and licenses from the local or national governments. We can be held liable for the illegal activities of our employees, representatives, contractors, partners, and agents, even if we do not explicitly authorize such activities. Any violation of the FCPA and other applicable anti-bribery laws and anti-money laundering laws could result in whistleblower complaints, adverse media coverage, investigations, loss of export privileges, severe criminal or civil sanctions, which could have a material adverse effect on our business, financial condition, cash flows and reputation. In addition, responding to any enforcement action may result in the diversion of management’s attention and resources, significant defense costs and other professional fees.

Turbulence in global financial markets and economies may adversely affect the solar industry, the demand for solar project products, and our operating results, financial condition. liquidity and profitability.

Demand for solar project products is influenced by macroeconomic factors, such as global economic conditions, the supply and the prices of other energy products, such as oil, coal and natural gas, as well as government regulations and policies concerning the public utility industry. A decrease in prices of fossil fuels, for example, could reduce demand for alternative forms of energy, such as solar power. We are also affected by changes in the solar power market and solar industry trends. We may be adversely affected by a volatile solar power market and industry conditions; in particular, the demand and prices for our solar power projects and electricity generated by our solar power projects may decline, which may reduce our revenues and profitability. On June 7, 2021 the NDRC announced that commencing from 2021, the DG projects deployed in commercial and industrial sites will not be entitled to any subsidiary from the Central Government. In addition, decreases in prices of other energies, such as oil, electricity and wind power, may also negatively affect the demand for solar power projects. The solar industry is also expected to continue to be highly competitive due to more new entrants to the solar project market and upstream solar manufacturing players moving to the downstream project business. If the supply of solar projects grows faster than demand, and if governments continue to reduce financial support for the solar industry, impose trade barriers or impose curtailments in the solar industry, demand for our projects, as well as our average selling price, could be materially and adversely affected which may reduce our revenues and profitability.

There may still be substantial uncertainties in the global credit and lending environment. If the demand for solar power projects deteriorates due to these macroeconomic factors or solar market and industry trends, our liquidity and financial condition, including our ability to refinance maturing liabilities and access the capital markets to meet liquidity needs, and the liquidity and financial condition of our customers may be adversely affected. Such development would delay and lengthen our cash collection cycles and negatively affect our operating results. Additionally, our ADS price may decrease if investors have concerns that our business, financial condition and results of operations will be negatively affected by a global economic downturn.

The solar market is still in development and the extent of acceptance of solar power projects remains uncertain. Historical and current market data on the solar power industry are not as readily available as those for established industries where trends can be assessed more reliably from data gathered over a longer period of time. In addition, demand for solar power projects has not developed as fast as many market players have anticipated although the solar industry continues to experience lower costs, improved efficiency and higher electricity output. Many factors may affect the viability of widespread adoption of solar power projects technology and demand for solar power projects, including:

If solar power projects technology is proven not viable for widespread adoption or the demand for solar power projects fails to develop sufficiently, our revenues may suffer and we may be unable to sustain our profitability.

As a British Virgin Islands corporation, our business could be harmed due to EU Finance ministers’ jurisdictional ratings.

EU Finance ministers rate jurisdictions for tax rates and tax transparency, governance and real economic activity. Countries that are viewed by such finance ministers as not adequately cooperating, including by not implementing sufficient standards in respect of the foregoing, may be put on a “grey list” or a “blacklist.” We are a British Virgin Islands corporation and as of December 31, 2022, the British Virgin Islands remained “white-listed” by the EU. However, on February 14, 2023, the British Virgin Islands, among other jurisdictions, were placed on the EU list of non-cooperative jurisdictions for tax purposes. The British Virgin Islands were blacklisted due to non-compliance with the Organisation For Economic Co-operation and Development’s standards on exchange of information following a review which took place during the period from 2016-2020 and which did not take into account (a) the necessary focus on the extensive reconstruction of the jurisdiction following Hurricane Irma in September 2017 nor (b) the more recent comprehensive changes to the corporate and other legislation in the British Virgin Islands designed to implement the required standards. Although we understand that the British Virgin Islands are committed to full cooperation with the EU and have secured a supplementary review which is due to take place in August 2023, following which it expects to be taken off the “blacklist” in October 2023, subject to review by the EU Council, there is no guarantee that such a reclassification will occur.

If the British Virgin Islands are not removed from the list and sanctions or other financial, tax or regulatory measures were applied by European Member States to countries on the list, our business could be harmed. Further, our leverage in negotiations with future business partners may be negatively impacted and we may experience difficulties with banking and financing in the future.

EU member states have agreed upon a set of measures, which they can choose to apply against grey- or blacklisted countries, including monitoring and audits, withholding taxes, special documentation requirements and anti-abuse provisions. The European Commission has stated it will continue to support member states’ efforts to develop a more coordinated approach to sanctions for the listed countries. EU legislation prohibits EU funds from being channeled or transited through entities in countries on the blacklist. Other jurisdictions in which we operate could also be put on the blacklist in the future.

Our business, prospects, financial condition, results of operations and cash flows may be adversely affected by developments that are beyond our control in other countries.

Our business, financial condition, results of operations and cash flows depend partially on the level of economic activity, government and foreign exchange policies and political and economic developments in our other principal targeted international markets outside of China, such as the United States, Poland, Hungary, Spain, France, UK, Germany and Italy. Our business, revenues and prospects, as well as our financial condition, results of operations, cash flows and the market price of our ADSs, may also be materially and adversely affected by developments in international markets relating to inflation, interest rates, currency fluctuations, government subsidies, taxation, expropriation, as well as any protectionism, exchange control regulations, price and wage controls, social instability or other political, economic or diplomatic developments. We have no control over these conditions and developments which could adversely affect us and our business, financial condition, results of operations and cash flows or the price or market of our ADSs. See additional risks in “Item 3. Key Information—D. Risk Factors—Risks Related to Our Business.”

Fluctuations in exchange rates may have a material adverse effect on your investment.

Our sales in China are denominated in Renminbi, and our international sales are generally denominated in U.S. dollars, Euros, British pounds and other local currencies. Our costs and capital expenditures are largely denominated in Renminbi and foreign currencies, including U.S. dollars and Euros. Fluctuations in exchange rates could affect our net profit margins and could result in foreign exchange and operating gains or losses. In addition, our foreign currency exchange losses may be magnified by PRC exchange control regulations that restrict our ability to convert Renminbi into foreign currencies.

The value of the Renminbi against the U.S. dollar, the Euros, British pounds and other currencies is affected by, among other things, changes in China’s political and economic conditions and China’s foreign exchange policies. In recent years, the exchange rates between Renminbi and U.S. dollars and other foreign currency have fluctuated, depending on the market supply and demand with reference to a basket of currencies. It is difficult to predict how long this current situation may last and when and how it may change again.

In addition, although we have not received any dividend from our operating subsidiaries in China since 2008, we may receive such dividends in the future. Any significant depreciation of the Renminbi against the U.S. dollar may have a material adverse effect on our revenues and financial condition, and the value of, and any dividends payable on, our shares. For example, to the extent that we need to convert U.S. dollars into Renminbi for our operations, appreciation of the Renminbi against the U.S. dollar would have an adverse effect on the Renminbi amount we receive from the conversion. Conversely, if we decide to convert our Renminbi into U.S. dollars for the purpose of making payments for dividends on our shares or for other business purposes, appreciation of the U.S. dollar against the Renminbi would have a negative effect on the U.S. dollar amount available to us. As a proportion of our revenue is paid to us in Euros and British pounds, fluctuation between the Euros and the Renminbi as well as British pounds and the Renminbi may also have a material effect on our results of operations.

Risks Related to Our ADSs and Shares

The market price for our ADSs may be volatile

The market price for our ADSs has been highly volatile and subject to wide fluctuations that are not related to the operating performance of the Company. During the period from January 29, 2008, the first day on which our ADSs were listed on the NYSE, until March 13, 2024, the market price of our ADSs ranged from $0.85 to $147.4 per ADS, after giving effect to the ADS Ratio Change. In more recent years, the market price of our ADSs was from $4.52 (closing price) as of December 31, 2022 to $2.73 (closing price) as of December 31, 2023. We cannot assure you that our share prices will not suffer from a dramatic drop in the future. If that happens, both our business operations and your interests may be adversely and materially affected. In addition, the market price of our ADSs may continue to be volatile and subject to wide fluctuations in response to a wide variety of factors including the following:

You should note that the stock prices of solar power companies have experienced wide fluctuations. Such wide market fluctuations may adversely affect the market price of our ADSs. The market price of the ADSs will likely continue to fluctuate in response to the factors discussed above, many of which are beyond our control.

In addition, the securities market has from time to time experienced significant price and volume fluctuations that are not related to the operating performance of particular companies. Such fluctuations have occurred since 2008 and have affected the trading price of our ADSs. Continued market fluctuations may materially and adversely affect the market price of our ADSs.

The NYSE may delist our ADSs from trading on its exchange which could limit investors’ ability to make transactions and subject us to additional trading restrictions.

Our ADSs are currently listed on the New York Stock Exchange (“NYSE”). If the NYSE were to delist our ADSs from trading on its exchange, we could face significant material adverse consequences, including:

On April 17, 2024, we received a notice from the NYSE indicating that the we were not in compliance with the NYSE’s continued listing requirements under the timely filing criteria outlined in Section 802.01E of the NYSE Listed Company Manual as a result of our failure to timely file our Annual Report on Form 10-K for the fiscal year ended December 31, 2023. If we are unable to regain and maintain compliance with the NYSE listed company rules, the market price of our securities could decline significantly.

We may need additional capital and may sell additional ADSs or other equity, equity-linked or debt securities or incur indebtedness, which could result in additional dilution to our shareholders or increase our debt service obligations.

We require a significant amount of cash to fund our operations due to changed business conditions or other future developments, including any investments or acquisitions we may decide to pursue, and repay our outstanding debt. We may issue additional equity, equity-linked or debt securities, or obtain a credit facility for a number of reasons, including to finance our operations and business strategy, to satisfy our obligations for the repayment of existing indebtedness, or for other reasons. Any future issuances of equity securities or equity-linked securities could further dilute the interests of our shareholders and may materially adversely affect the price of our ADSs. We cannot predict the timing or size of any future issuances or sales of equity, equity-linked or debt securities, or the effect, if any, that such issuances or sales may have on the market price of our ADSs. We also cannot be sure that we will not need to raise additional capital in the future as a result of continuing or worsening economic conditions or otherwise. Market conditions could require us to accept less favorable terms for the issuance of our securities in the future, which may result in the issuance of securities that have rights, preferences and privileges that are senior to those of the shares and ADSs. The incurrence of indebtedness would result in increased debt service obligations and could result in operating and financing covenants that would restrict our operations. We cannot assure you that financing will be available in amounts or on terms acceptable to us, if at all.

Future issuance of shares or ADSs may adversely affect the price of the ADSs.

We may from time to time access the capital market to raise capital. In addition, we have reserved our shares and ADSs for the holders’ exercise of our share options which are granted pursuant to our 2007 share incentive plan. All ADSs sold in our initial public offering and the follow-on offerings are freely transferable without restriction or additional registration under the Securities Act of 1933, as amended, or the Securities Act. The remaining ADSs outstanding after the initial public offering and the follow-on offerings are currently available for sale, subject to volume and other restrictions as applicable under Rule 144 and Rule 701 of the Securities Act. The issuance and sale of a substantial number of shares or ADSs, or the perception that such issuances and sales may occur, could adversely affect the market price of the shares or ADSs and impair our ability to raise capital through the sale of additional equity securities.

The depository for our ADSs may give us a discretionary proxy to vote our shares underlying your ADSs if you do not give voting instructions, which could adversely affect your interests.

Under the deposit agreement for the ADSs, if we asked for your instructions but the depositary does not receive your instructions by the cutoff date it sets, the depositary will give us a discretionary proxy to vote the shares underlying your ADSs as to all matters at the shareholders’ meeting unless:

The effect of this discretionary proxy is that if you do not give voting instructions, you cannot prevent the shares underlying your ADSs from being voted, except in the circumstances described above. This arrangement may make it more difficult for shareholders to influence the management of our company. Holders of our shares are not subject to this discretionary proxy.

You may be subject to limitations on transfer of your ADSs.

Your ADSs represented by the ADRs are transferable on the books of the depositary. However, the depositary may close its transfer books from time to time when it deems that it is expedient for the performance of its duties. In addition, the depositary may refuse to deliver, transfer or register transfers of ADSs generally when our books or the books of the depositary are closed, or at any time if we or the depositary deem it advisable to do so because of any requirement of law or of any government or governmental body, or under any provision of the deposit agreement, or for any other reason.

We may be a passive foreign investment company for U.S. Federal income tax purposes, which could result in adverse U.S. Federal income tax consequences to U.S. Holders of our ADSs or shares.

We will be a passive foreign investment company, or PFIC, for U.S. federal income tax purposes for any taxable year if, applying applicable look-through rules, either (i) at least 75% of our gross income for such year is passive income or (ii) at least 50% of the value of our assets (generally determined based on an average of the quarterly values of the assets) during such year is attributable to assets that produce or are held for the production of passive income. A separate determination must be made after the close of each taxable year as to whether we were a PFIC for that year. Although the application of the PFIC rules is unclear in many important respects and the required calculations yield results very close to the line, based on the market price of our ADSs, the value of our assets, and the composition of our income and assets, we do not believe that we were a PFIC for our taxable year ended December 31, 2022, but there can be no assurances in this regard. The determination of PFIC status involves extensive factual investigation, including ascertaining the fair market value of all of our assets on a quarterly basis and the character of each item of income that we earn, and is subject to uncertainty in several respects. Accordingly, we cannot guarantee that the U.S. Internal Revenue Service, or IRS, will agree with any positions that we take or that we will not be treated as a PFIC for our taxable year ended December 31, 2022, the current taxable year or any future taxable year.

While we do not expect to be or become a PFIC, no assurance can be given in this regard because the determination of whether we are or will become a PFIC for any taxable year is a fact-intensive inquiry made on an annual basis that depends, in part, upon the composition and classification of our income and assets. Fluctuations in the market prices of our ADSs and ordinary shares may cause us to be or become a PFIC for the current or subsequent taxable years because the value of our assets for the purpose of the asset test, may be determined by reference to the market price of our ADSs from time to time (which may be volatile). The composition of our income and assets may also be affected by how, and how quickly, we use our liquid assets.

We face a number of risks involving EMCs, PPAs and project-level financing arrangements, including failure or delay in entering into PPAs, defaults by counterparties and contingent contractual terms such as price adjustment, termination, buy-out, acceleration or other clauses, all of which could materially and adversely affect our business, financial condition, results of operations and cash flows.

We may not be able to enter into PPAs for our solar power projects due to intense competition, increased supply of electricity from other sources, reduction in retail electricity price, changes in government policies or other factors. There may be a limited pool of potential purchasers in some jurisdictions for electricity generated by our solar power plants due to regulatory policies. The willingness of purchasers to purchase electricity from an IPP like us may be based on a number of factors and not solely on pricing and surety of supply. If we cannot enter into PPAs on terms favorable to us, or at all, it would negatively impact our revenue and our decisions regarding the development of additional power plants. We may experience delays in entering into PPAs for some of our solar power projects or may not be able to replace an expiring PPA with a contract on equivalent terms and conditions, or otherwise at prices that permit operation of the related facility on a profitable basis. Any delay in entering into PPAs may adversely affect our cash flows generated by such projects. If we are unable to replace an expiring PPA with an acceptable new PPA, the affected site may temporarily or permanently cease operations, which could materially and adversely affect our financial condition, results of operations and cash flows.

Substantially all of the electricity generated by our solar power projects will be sold under long-term PPAs with government end users and a few to licensed suppliers or commercial and industrial users. We expect our future projects will also have long-term public PPAs or similar offtake arrangements such as tariff programs but the portion under licensed suppliers or commercial and industrial users may increase due to our focus in DG projects, and also due to the falling system cost which makes solar energy more accessible to non-State Grid users such as commercial and industrial users. If any of the purchasers of power under these contracts are unable or unwilling to fulfill their related contractual obligations, they refuse to accept delivery of power delivered thereunder, or they otherwise terminate such agreements prior to the expiration thereof, our assets, liabilities, business, financial condition, results of operations and cash flows could be materially and adversely affected. Further, to the extent any of our power purchasers are, or are controlled by, governmental entities, our facilities may be subject to legislative or other political action that may impair their contractual performance or contain contractual remedies that do not provide adequate compensation in the event of a counterparty default.

Some of our PPAs are subject to price adjustments over time or to inflation and some of our long-term PPAs do not include inflation-based price increases or other price adjustment clauses. Certain of the PPAs for our projects and those for projects that we have acquired and may acquire in the future contain or may contain provisions that allow the offtake purchaser to terminate or buy out the project or require us to pay liquidated damages upon the occurrence of certain events. If the price under any of our PPAs is reduced below a level that makes a project economically viable, or if the termination, buy-out or liquidated damages provisions are exercised, our financial condition, results of operations and cash flows could be materially and adversely affected.

In addition, certain of the project-level financing arrangements for projects allow, and certain of the projects that we may acquire in the future may allow, the lenders or investors to accelerate the repayment of the financing arrangement in the event that a PPA is terminated or if certain operating thresholds or performance measures are not achieved within specified time periods if we do not timely notify the lenders and investors of such event and fail to provide any required additional guarantee. Certain of our PPAs and project-level financing arrangements include, and in the future may include, provisions that would permit the counterparty to terminate the contract or accelerate maturity in the event we own, directly or indirectly, less than 50% of the combined voting power or, in some cases, if we cease to be the majority owner, directly or indirectly, of the applicable project subsidiary. The termination of any of our PPAs or the acceleration of the maturity of any of our financing arrangements as a result of a change-in-control event could have a material adverse effect on our financial condition, results of operations and cash flows.

Before we can supply the electricity to our power purchasers, we are required to enter into the grid connection and dispatch agreements with the grid providers and energy management contracts, or EMCs, including PPAs with the power purchasers. If we are unable to renew the agreements upon expiration, we may not be able to replace them with agreements with equivalent terms and conditions, or at all, or we may experience significant delays or costs related to securing replacements. If we are unable to agree with the grid providers on a new grid connection and dispatch agreements, the affected solar power project may temporarily or permanently cease operations, and we may not be able to operate the project beyond the initial term of the EMCs and PPAs. In addition, if, for any reason, the grid providers are unable or unwilling to fulfill their related contractual obligations or if they refuse to accept delivery of electricity delivered thereunder or otherwise terminate such agreements prior to the expiration thereof, our business, financial condition, results of operations and cash flow could be materially adversely affected.

Volatility in the prices of solar power projects may cause significant fluctuations or declines in our revenue.

The prices of project SPVs and solar power projects are primarily based on the electricity revenue the projects can generate and the rate of returns. The electricity price may vary. Investors may compare the rate of returns generated from solar power projects with the rate of returns in the financing or investment markets. Any significant volatility or decreases in the electricity price or rate of return may decrease the prices of solar power projects, which may subject us to significant fluctuations or declines in our revenue.

If we fail to maintain an effective system of internal controls, we may be unable to accurately report our financial results or prevent fraud and investor confidence and the market price of our ADSs may be adversely impacted.

We are subject to reporting obligations under the U.S. securities laws. The Securities and Exchange Commission, or the SEC, as required by Section 404 of the Sarbanes-Oxley Act of 2002, or the Sarbanes-Oxley Act, adopted rules requiring every public company to include a management report on the effectiveness of such company’s internal control over financial reporting in its annual report.

A system of financial controls and procedures is necessary to ensure that information about our financial results is recorded, processed, summarized, and reported in an accurate and timely fashion. Effective internal control over financial reporting is necessary for us to provide reliable financial reports and prevent fraud. If we cannot disclose required information or provide reliable financial reports, we may not be able to manage our business as effectively as we would if an effective control environment existed, and our business and reputation may be harmed.

In connection with management’s assessment of the effectiveness of our internal control over financial reporting for the year ended December 31, 2023, our management identified material weaknesses in our internal control over financial reporting that as of December 31, 2023, our disclosure controls and procedures and our internal control over financial reporting were ineffective.

The material weaknesses identified in our internal control over financial reporting as of December 31, 2023 related to the ineffective review and approval procedures over preparation of financial reporting at certain of our subsidiary locations. In addition, we noted certain instances where some historical accounting supporting documents were not readily available. We noted that the Company improperly offset refundable deposits on leases against lease liabilities in the consolidated financial statements presentation related to Accounting Standards Codification 842, Leases (“ASC 842”), in which refundable deposits on leases should be reflected as an asset on the consolidated balance sheet. We concluded that the failure to timely identify such accounting errors constituted material weakness as defined in the SEC regulations. As such, management determined that our disclosure controls and procedures were not effective as of December 31, 2023.

We have limited insurance coverage and may incur losses resulting from product liability claims or business interruptions.

We currently maintain property insurance and machine damage insurance for all the projects we operate, and director and officer liability insurance. We may also maintain other insurance, including commercial general liability insurance, public liability insurance, construction insurance, and builder risks insurance depending on our financing needs. We do not maintain any insurance for business interruption. Any business disruption or natural disaster could result in substantial costs and a diversion of resources, which would have an adverse effect on our business and results of operations. We are also exposed to risks associated with product liability claims if the use of our solar power projects results in injury. We cannot predict whether product liability claims will be brought against us in the future or the effect of any resulting negative publicity on our business. The successful assertion of product liability claims against us could result in potentially significant monetary damages.

You may face difficulties in protecting your interests, and your ability to protect your rights through the U.S. federal courts may be limited, because we are incorporated under British Virgin Islands law, conduct some of our operations in China and Europe, and some of our officers and directors reside outside the United States.

We are incorporated in the British Virgin Islands and conduct substantially all of our operations in China, United States and Europe through our subsidiaries. Some of our directors and officers reside outside of the United States, and some or all of the assets of those persons are located outside of the United States. As a result, it may be difficult or impossible for you to bring an original action against us or against these individuals in a British Virgin Islands or China court in the event that you believe that your rights have been infringed under the U.S. federal securities laws or otherwise. It may also be difficult for you to enforce in U.S. courts judgments obtained in U.S. courts based on the civil liability provisions of the U.S. federal securities laws against us and our officers and directors. In addition, there is uncertainty as to whether the courts of the British Virgin Islands or China would recognize or enforce judgments of U.S. courts against us or such persons predicated upon the civil liability provisions of the securities laws of the United States or any state. There is no statutory recognition in the British Virgin Islands of judgments obtained in the United States, although the courts of the British Virgin Islands will generally recognize and enforce a non-penal judgment of a foreign court of competent jurisdiction without retrial on the merits. It is uncertain whether such British Virgin Islands or China courts would be competent to hear original actions brought in the British Virgin Islands or China against us or such persons predicated upon the securities laws of the United States or any state.

Our corporate affairs are governed by our memorandum and articles of association and by the BVI Business Companies Act, 2004 and common law of the British Virgin Islands. The rights of shareholders to take legal action against our directors and us, actions by minority shareholders and the fiduciary responsibilities of our directors to us under British Virgin Islands law are to a large extent governed by the common law of the British Virgin Islands. The common law of the British Virgin Islands is derived in part from comparatively limited judicial precedent in the British Virgin Islands as well as from the common law in England and other countries in the Commonwealth, which has persuasive, but not binding, authority on a court in the British Virgin Islands. The rights of our shareholders and the fiduciary responsibilities of our directors under British Virgin Islands law are not as clearly established as they would be under statutes or judicial precedents in the United States. In particular, the British Virgin Islands has no securities laws as compared to the United States and provides significantly less protection to investors. In addition, British Virgin Islands companies may not have standing to initiate a shareholder derivative action before the federal courts of the United States.

We conduct a large portion of our business through our subsidiaries incorporated in China. These subsidiaries are generally subject to laws and regulations applicable to foreign investment in China. The PRC legal system is based on written statutes. Prior court decisions may be cited for reference but have limited precedential value. The PRC legal system continues to rapidly evolve, the interpretations of many laws, regulations and rules are not always uniform and enforcement of these laws, regulations and rules involve uncertainties, which may limit legal protections available. In addition, any litigation in China may be protracted and result in substantial costs and diversion of resources and management attention, which could adversely affect our business.

As a result of all of the above, our public shareholders may have more difficulties in protecting their interests through actions against our management, directors or major shareholders than would shareholders of a corporation incorporated in a jurisdiction in the United States.

Our existing principal shareholders have substantial influence over our Company, and their interests may not be aligned with the interests of our other shareholders.

Mr. Himanshu H. Shah, our chairman of the Board, beneficially owned about 34.15% of our shares. Mr. Shah serves as President and Chief Investment Officer of Shah Capital Management, Inc., which beneficially owned 34.02% of our shares. Shah Capital Management, Inc. serves as investment adviser to Shah Capital Opportunity Fund LP, which beneficially owned 33.34% of our shares. Additionally, under the Amended and Restated Investor Rights Agreement, Shah Capital Opportunity Fund LP has rights to nominate three designees for election and/or appointment to the Board. As such, Mr. Shah has substantial influence over our business, including decisions regarding mergers, consolidations and the sale of all or substantially all of our assets, election of directors and other significant corporate actions. This concentration of ownership may discourage, delay or prevent a change in control of our company, which could deprive our shareholders of an opportunity to receive a premium for their shares as part of a sale of our company and might reduce the price of our ADSs. For example, holders of a majority of our shares entitled to vote in a duly convened and constituted shareholders’ meeting may pass a shareholders’ resolution to permit the issuance of preferred shares in one or more series and to fix the powers and rights of these shares, including dividend rights, conversion rights, voting rights, terms of redemption and liquidation preferences, any or all of which may be greater than the rights associated with our existing shares. Preferred shares could thus be issued with terms that would delay or prevent a change in control. These actions may be taken even if they are opposed by our other shareholders and holders of our ADSs.

As a holder of our ADSs, you may not have the same voting rights as holders of our shares, may not receive voting materials in time to be able to exercise your right to vote and the depository may give us a discretionary proxy to vote our shares underlying your ADSs if you do not give voting instructions, which could adversely affect your interests.

ADS holders do not have the same rights as our shareholders and may only exercise voting rights with respect to underlying shares in accordance with the deposit agreement. When a general meeting is convened, ADS holders may not receive sufficient notice of a shareholders’ meeting to withdraw their shares and cast their vote. In addition, the depositary and its agents may not be able to send voting instructions to ADS holders or carry out ADS holders’ voting instructions in a timely manner. We will make all reasonable efforts to cause the depositary to extend voting rights to ADS holders in a timely manner. Furthermore, the depositary and its agents will not be responsible for any failure to carry out any instructions to vote, the how a vote is cast, or the effect of any such vote. As a result, you may not be able to exercise your right to vote. In addition, ADS holders are not able to call a shareholder meeting.

Further, under the deposit agreement, if we asked for the ADS holder’s instructions but the depositary does not receive instructions by its cutoff date, the depositary will give us a discretionary proxy to vote the underlying shares as to all matters at the shareholders’ meeting unless (i) we instructed the depositary we do not wish to receive a discretionary proxy; (ii) we informed the depositary that there is substantial opposition to the particular matter; or (iii) the particular matter would have a material adverse impact on shareholders. If you do not give voting instructions, you cannot prevent the shares underlying your ADSs from being voted, except in the circumstances described above. This arrangement may make it more difficult for shareholders to influence the management of our company. Holders of our shares are not subject to this discretionary proxy.

You may not be able to participate in rights offerings and may experience dilution of your holdings as a result.

We may from time to time distribute rights to our shareholders, including rights to acquire our securities. However, we cannot make rights available to ADS holders in the United States unless we register the rights and the securities to which the rights relate under the Securities Act or an exemption from the registration requirements is available. Under the ADS deposit agreement, the depositary will not offer those rights available to ADS holders unless the distribution to ADS holders of both the rights and any related securities are either registered under the Securities Act or exempt from registration under the Securities Act with respect to all ADS holders. We are under no obligation to file a registration statement with respect to any such rights or underlying securities or to endeavor to cause such a registration statement to be declared effective. In addition, we may not be able to take advantage of any exemptions from registration under the Securities Act. If we conduct any future rights offering, the depositary may not make such rights available to ADS holders or may dispose of such rights and make the net proceeds available to such holders. As a result, ADS holders may be unable to participate in our rights offerings and may experience dilution in their holdings.

If a United States person is treated as owning at least 10% of our ADSs or shares, such person may be subject to adverse U.S. federal income tax consequences.

If a United States person is treated as owning (directly, indirectly or constructively) at least 10% of the value or voting power of our ADSs or ordinary shares, such person may be treated as a “United States shareholder” with respect to each “controlled foreign corporation” in the Company’s group. Where the Company’s group includes one or more U.S. subsidiaries, in certain circumstances we could be treated as a controlled foreign corporation and certain of our non-U.S. subsidiaries could be treated as controlled foreign corporations (regardless of whether we are or are not treated as a controlled foreign corporation). A United States shareholder of a controlled foreign corporation may be required to annually report and include in its U.S. taxable income its pro rata share of “Subpart F income,” “global intangible low-taxed income” and investments in U.S. property by controlled foreign corporations, whether or not we make any distributions. An individual that is a United States shareholder with respect to a controlled foreign corporation generally would not be allowed certain tax deductions or foreign tax credits that would be allowed to a United States shareholder that is a U.S. corporation. A failure to comply with these reporting obligations may subject a United States shareholder to significant monetary penalties and may prevent starting of the statute of limitations with respect to such shareholder’s U.S. federal income tax return for the year for which reporting was due. We do not intend to monitor whether we or any of our non-U.S. subsidiaries are treated as a controlled foreign corporation or whether any investor is treated as a United States shareholder with respect to us or any of our subsidiaries or to furnish to any United States shareholders information that may be necessary to comply with the aforementioned reporting and tax paying obligations. A United States investor should consult its own advisor regarding the potential application of these rules in its particular circumstances.

Because we have ceased to qualify as a foreign private issuer, we are required to comply fully with the reporting requirements of the Exchange Act applicable to U.S. domestic issuers, and we will incur significant additional legal, accounting, and other expenses that we would not incur as a foreign private issuer.

We are no longer a foreign private issuer and are no longer exempt from rules under the Exchange Act that are applicable to U.S. domestic public companies, including (i) sections of the Exchange Act regulating the solicitation of proxies, consents or authorizations in respect of a security registered under the Exchange Act; (ii) sections of the Exchange Act requiring insiders to file public reports of their share ownership and trading activities and liability for insiders who profit from trades made in a short period of time; (iii) rules under the Exchange Act requiring quarterly reports on Form 10-Q and annual reports on Form 10-K; and (iv) Regulation FD, which is intended to prevent issuers from making selective disclosures of material information. As a result, we will incur significant additional legal, accounting, and other expenses that we would not incur as a foreign private issuer.

Item 1B. Unresolved Staff Comments

None.

Item 1C. Cybersecurity

For purposes of Item 106 of Regulation S-K, “cybersecurity threat” means any potential unauthorized occurrence on or conducted through a company’s information systems that may result in adverse effects on the confidentiality, integrity or availability of a company’s information systems or any information residing therein.

A “cybersecurity incident” means an unauthorized occurrence, or a series of related unauthorized occurrences, on or conducted through a company’s information systems that jeopardizes the confidentiality, integrity or availability of a company’s information systems or any information residing therein.

The term “information systems” means electronic information resources, owned or used by the company, including physical or virtual infrastructure controlled by such information resources, or components thereof, organized for the collection, processing, maintenance, use, sharing, dissemination or disposition of the company’s information to maintain or support the company’s operations.

The Company’s Board of Directors (the “Board”) recognizes the critical importance of maintaining the trust and confidence of our customers, clients, business partners and employees. The Board is actively involved in oversight of the Company’s risk management program, and cybersecurity represents an important component of the Company’s overall approach to enterprise risk management (“ERM”). The Company’s cybersecurity policies, standards, processes, and practices are fully integrated into the Company’s ERM program and are based on recognized frameworks established by the National Institute of Standards and Technology, the International Organization for Standardization and other applicable industry standards. In general, the Company seeks to address cybersecurity risks through a comprehensive, cross-functional approach that is focused on preserving the confidentiality, security and availability of the information that the Company collects and stores by identifying, preventing and mitigating cybersecurity threats and effectively responding to cybersecurity incidents when they occur.

Risk Management and Strategy

As one of the critical elements of the Company’s overall ERM approach, the Company’s cybersecurity program is focused on the following key areas:

Governance: As discussed in more detail under the heading “Governance,” The Board’s oversight of cybersecurity risk management is supported by the Risk Management Committee of the Board (the “Risk Management Committee”), which regularly interacts with the Company’s ERM function, other members of management and relevant management committees and councils, including management’s Cybersecurity Council.

Collaborative Approach: The Company has implemented a comprehensive, cross-functional approach to identifying, preventing and mitigating cybersecurity threats and incidents, while also implementing controls and procedures that provide for the prompt escalation of certain cybersecurity incidents so that decisions regarding the public disclosure and reporting of such incidents can be made by management in a timely manner.

Technical Safeguards: The Company deploys technical safeguards that are designed to protect the Company’s information systems from cybersecurity threats, including firewalls, intrusion prevention and detection systems, anti-malware functionality and access controls, which are evaluated and improved through vulnerability assessments and cybersecurity threat intelligence.

Incident Response and Recovery Planning: The Company has established and maintains comprehensive incident response and recovery plans that fully address the Company’s response to a cybersecurity incident, and such plans are tested and evaluated on a regular basis.

Third-Party Risk Management: The Company maintains a comprehensive, risk-based approach to identifying and overseeing cybersecurity risks presented by third parties, including vendors, service providers and other external users of the Company’s systems, as well as the systems of third parties that could adversely impact our business in the event of a cybersecurity incident affecting those third-party systems.

Education and Awareness: The Company provides regular, mandatory training for personnel regarding cybersecurity threats as a means to equip the Company’s personnel with effective tools to address cybersecurity threats, and to communicate the Company’s evolving information security policies, standards, processes and practices.

The Company engages in the periodic assessment and testing of the Company’s policies, standards, processes and practices that are designed to address cybersecurity threats and incidents. These efforts include a wide range of activities, including audits, assessments, tabletop exercises, threat modeling, vulnerability testing and other exercises focused on evaluating the effectiveness of our cybersecurity measures and planning. The Company regularly engages third parties to perform assessments on our cybersecurity measures, including information security maturity assessments, audits and independent reviews of our information security control environment and operating effectiveness. The results of such assessments, audits and reviews are reported to the Risk Management Committee and the Board, and the Company adjusts its cybersecurity policies, standards, processes and practices as necessary based on the information provided by these assessments, audits and reviews.

Governance

The Board, in coordination with the Risk Management Committee, oversees the Company’s ERM process, including the management of risks arising from cybersecurity threats. The Board and the Risk Management Committee each receive regular presentations and reports on cybersecurity risks, which address a wide range of topics including recent developments, evolving standards, vulnerability assessments, third-party and independent reviews, the threat environment, technological trends and information security considerations arising with respect to the Company’s peers and third parties. The Board and the Risk Management Committee also receive prompt and timely information regarding any cybersecurity incident that meets established reporting thresholds, as well as ongoing updates regarding any such incident until it has been addressed. On an annual basis, the Board and the Risk Management Committee discuss the Company’s approach to cybersecurity risk management with the members of the Cybersecurity Council, which includes the Company’s Information Technology Engineer (“IT Engineer”).

The IT Engineer, in coordination with the Cybersecurity Council, which includes our Chief Executive Officer (“CEO”), Chief Financial Officer (“CFO”) and Compliance Director works collaboratively across the Company to implement a program designed to protect the Company’s information systems from cybersecurity threats and to promptly respond to any cybersecurity incidents in accordance with the Company’s incident response and recovery plans. To facilitate the success of the Company’s cybersecurity risk management program, multidisciplinary teams throughout the Company are deployed to address cybersecurity threats and to respond to cybersecurity incidents. Through ongoing communications with these teams, the IT Engineer and the Cybersecurity Council monitor the prevention, detection, mitigation and remediation of cybersecurity threats and incidents in real time and report such threats and incidents to the Risk Management Committee when appropriate.

The Company’s IT Engineer, CEO, CFO and Compliance Director each hold undergraduate and graduate degrees in their respective fields, and each have over 25 years of experience managing risks at the Company and at similar companies, including risks arising from cybersecurity threats.

Previous cybersecurity incidents have not materially affected us, including our business strategy, results of operations or financial condition. However, risks from cybersecurity threats could harm our business and could have a material adverse effect on our business, prospects, liquidity, financial condition and results of operations. See “Information system failures, cyber incidents or breaches in security could adversely affect us” under Item 1A Risk Factors for a discussion of cybersecurity risks.

Item 2.Properties

Our principal executive offices are located at 100 First Stamford Place, Suite 302, Stamford, CT 06902, U.S.A. Our registered office is located at the offices of Harneys Corporate Services Limited, Craigmuir Chambers, P.O. Box 71, Road Town, Tortola, VG1110, British Virgin Islands. Our agent for service of process in the United States is CT Corporation System, located at 111 Eighth Avenue, New York, New York 10011. As of December 31, 2023, we conduct our business primarily through the following subsidiaries, offices, and registered business entities:

British Virgin Islands (BVI):

Luxembourg:

United States of America (USA):

Canada:

Austria:

Poland:

Hungary:

France:

Spain:

United Kingdom (UK):

Italy:

Germany:

China:

Item 3.Legal Proceedings

Emeren Group Ltd. is not involved in any litigation or other legal proceedings that we believe would have a material adverse impact on our business or operations as of the date of this annual report. Emeren Group Ltd. may from time to time be subject to various judicial or administrative proceedings arising in the ordinary course of our business. While Emeren Group Ltd. does not expect the proceedings described above to have a material adverse effect on our financial position, profitability, results of operations or cash flows, the outcome of any proceedings is not determinable with certainty and negative outcomes may have a material adverse effect on our business or operations.

Item 4.Mine Safety Disclosures

Not applicable.

​

In February, 2024, we announced that our Board of Directors approved an accelerated stock repurchase (ASR) program of up to $10 million, which does not expire. This accelerated stock repurchase program underscores the Board’s commitment to our shareholders and confidence in the company’s future growth.

Sales of Unregistered Securities

None.

Item 6.[Reserved]

​

Item 7.Management’s Discussion and Analysis of Financial Condition and Results of Operations

The following management’s discussion and analysis describes the principal factors affecting our capital resources, liquidity, and results operations. This management’s discussion and analysis should be read in conjunction with the accompanying Financial Statements and related notes, information about our business practices, significant accounting policies, risk factors, and the transactions that underlie our financial results, which are included in various parts of this Annual Report. Certain statements in our discussion below are forward-looking statements. These forward-looking statements involve risks and uncertainties. We caution that a number of factors could cause actual results to differ materially from those implied or expressed by the forward-looking statements. Please see “Cautionary Statement Regarding Forward-Looking Statements” and “Item 1A. Risk Factors” for further details about these statements.

Overview

You should read the following discussion and analysis in conjunction with our financial statements and the related notes appearing elsewhere in this annual report on Form 10-K. This discussion may contain forward-looking statements based on current expectations that involve risks and uncertainties. Our actual results may differ materially from those anticipated in these forward-looking statements as a result of various factors, including those set forth under “Item 1A.- Risk Factors” or in other parts of this annual report on Form 10-K.

We closed 2023 with $105.6 million of revenue, 23.7% gross margin and $3.2 million net loss attributed to Emeren Group Ltd. These results were below our full-year guidance primarily due to delays in closing 6 project sales developments projects in U.S. and Europe, which are now expected to close in 2024. Our 2023 results were further impacted by several one-time write-offs and continued government related delays. We continue to face disruptions due to higher interest rates, utility scale delays from transmission and Europe regulation uncertainty.

Despite these challenges, we remain focused on executing our core solar project development strategy, diversify of our global footprint and advancing our positioning as a leading global solar company. We monetized approximately 130 MW of solar projects and over 1 GWh storage projects in 2023.

During 2023, we began implementing strategic cost control initiatives throughout our U.S. and European operations aimed at enhancing efficiency and optimizing resource allocation. In the United States, these measures include workforce reductions, lean management policies, and halting certain early-stage developments to concentrate efforts and resources on advanced stage projects. This shift aims to reduce overhead associated with early-stage explorations and allocate personnel more effectively towards projects with higher likelihood of success, improved profitability, and shorter development cycles.

In addition, in February, 2024, we announced that our Board of Directors approved an accelerated stock repurchase (ASR) program of up to $10 million. This accelerated stock repurchase program underscores the Board’s commitment to our shareholders and confidence in the company’s future growth. With our expertise in solar project development, strong industry network, and solid balance sheet, we are making significant progress towards becoming an industry leading global solar and storage developer. Our strategic focus remains on maintaining a lean cost structure and achieving sustainable profitability, while monetizing our extensive advance-stage project pipeline.

Looking Forward

Looking forward to 2024 and beyond, we believe that we are well positioned in many of the world’s fastest growing solar markets that are benefiting from increasing demand for clean energy and supportive government policies and technology trends.

The solar industry continues to experience strong tailwinds, driven by the global commitment to renewable energy and sustainability. Governments and corporations worldwide are setting ambitious targets for reducing carbon emissions, which in turn fuels significant demand for solar energy solutions. This commitment is part of a broader shift towards cleaner, more sustainable energy sources, positioning solar energy as a key player in the global energy mix.

One of the most exciting developments in the renewable energy sector is the booming demand for solar power to support artificial intelligence (AI) operations. As AI technologies become increasingly integrated into our daily lives and business operations, the energy required to power these advanced systems is substantial. Solar energy, with its scalability and decreasing cost profile, is becoming a preferred source of power for these high-tech applications, further driving demand in the sector.

In conclusion, the future of solar energy is extremely promising, and we are positioned to fully capitalize on the accelerating adoption of solar technology across the globe. With our exceptional expertise in developing and operating solar projects, extensive network of industry partnerships, and strong financial position, we are making great strides towards our goal of becoming a top global solar company. We are thrilled about the bright future of solar energy and are excited to be at the forefront of this incredible transformation towards a more sustainable future.

Our net revenue increased from $61.3 million in 2022 to $105.6 million in 2023. We recorded an operating loss of $8.7 million and net loss attributed to Emeren Group Ltd of $3.2 million in 2023, compared to an operating loss of $2.6 million and net loss attributed to Emeren Group Ltd of $4.7 million in 2022. Net loss attributed to Emeren Group Ltd per ADS was $0.06 in 2023, compared to net loss attributed to Emeren Group Ltd per ADS of $0.07 in 2022.

Overview of Financial Results

Net Revenue

We are a solar/storage project developer and operator, with our revenues mainly generated from our solar/storage power projects. Set forth below is the breakdown of our net revenue by segment in absolute amount.

The Company has three reportable segments, including solar/storage power project development, EPC services and electricity generation. Ancillary revenues and expenses and other unallocated costs and expenses are recorded in other.