| CONTINGENT LIABILITIES AND OTHER MATTERS | CONTINGENT LIABILITIES AND OTHER MATTERS General Numerous claims, complaints and proceedings arising in the ordinary course of business have been asserted or are pending against us or certain of our subsidiaries (collectively, “claims”). These claims relate to litigation matters (e.g., class actions, derivative lawsuits and contracts, intellectual property and competitive claims), environmental matters, product liability matters (which, prior to the Asbestos Portfolio Sale, were predominately associated with alleged exposure to asbestos-containing materials), and other risk management matters (e.g., general liability, automobile, and workers’ compensation claims). Additionally, we may become subject to other claims of which we are currently unaware, which may be significant, or the claims of which we are aware may result in our incurring significantly greater loss than we anticipate. While we (and our subsidiaries) maintain property, cargo, auto, product, general liability, environmental, and directors’ and officers’ liability insurance and have acquired rights under similar policies in connection with acquisitions that we believe cover a significant portion of these claims, this insurance may be insufficient or unavailable (e.g., in the case of insurer insolvency) to protect us against potential loss exposures. Also, while we believe we are entitled to indemnification from third parties for some of these claims, these rights may be insufficient or unavailable to protect us against potential loss exposures. Our recorded liab ilities related to these matters totaled $38.9 and $39.5 at April 1, 2023 and December 31, 2022, respectively. Of these amounts, $31.6 and $30.8 are included in “Other long-term liabilities” within our condensed consolidated balance sheets at April 1, 2023 and December 31, 2022 , respectively, with the remainder included in “Accrued expenses.” The liabilities we record for these matters are based on a number of assumptions, including historical claims and payment experience. While we base our assumptions on facts currently known to us, they entail inherently subjective judgments and uncertainties. As a result, our current assumptions for estimating these liabilities may not prove accurate, and we may be required to adjust these liabilities in the future, which could result in charges to earnings. These variances relative to current expectations could have a material impact on our financial position and results of operations. Asbestos Matters As indicated in Note 1, we completed the Asbestos Portfolio Sale on November 1, 2022, which resulted in the divestiture of three wholly-owned subsidiaries that hold asbestos liabilities and certain assets, including related insurance assets. As a result of this transaction, the Company divested all obligations with respect to pending and future asbestos claims relating to these subsidiaries. During the three months ended April 2, 2022 , our payments for asbestos-related claims, net of respective insurance recoveri es of $7.4, were $7.2 . During the three months ended April 2, 2022 , there were no other changes in estimates associated with our assets and liabilities related to our asbestos product liability matters. Large Power Projects in South Africa Overview - Since 2008, DBT had been executing on two large power projects in South Africa (Kusile and Medupi), on which it has substantially completed its scope of work. Over such time, the business environment surrounding these projects was difficult, as DBT, along with many other contractors on the projects, experienced delays, cost over-runs, and various other challenges associated with a complex set of contractual relationships among the end customer, prime contractors, various subcontractors (including DBT and its subcontractors), and various suppliers. DBT’s remaining responsibilities relate largely to resolution of various claims, primarily between itself and one of its prime contractors, Mitsubishi Heavy Industries Power—ZAF (f.k.a. Mitsubishi-Hitachi Power Systems Africa (PTY) LTD), or “MHI.” The challenges related to the projects have resulted in (i) significant adjustments to our revenue and cost estimates for the projects, (ii) DBT’s submission of numerous change orders to the prime contractors, (iii) various claims and disputes between DBT and other parties involved with the projects (e.g., prime contractors, subcontractors, suppliers, etc.), and (iv) the possibility that DBT may become subject to additional claims, which could be significant. It is possible that some outstanding claims may not be resolved until after the prime contractors complete their scopes of work. Our future financial position, operating results, and cash flows could be materially impacted by the resolution of current and any future claims. Claims by DBT - DBT has asserted claims against MHI of approximately South African Rand 1,000.0 (or $55.3 ). As DBT prepares these claims for dispute resolution processes, the amounts, along with the characterization, of the claims could change. Of these claims, South African Rand 606.0 (or $33.5 ), which is inclusive of the amounts awarded in the adjudications referred to below, are currently proceeding through contractual dispute resolution processes and DBT is likely to initiate additional dispute resolution processes. DBT is also pursuing several claims to force MHI to abide by its contractual obligations and provide DBT with certain benefits that MHI may have received from its customer on the projects. In addition to existing asserted claims, DBT believes it has additional claims and rights to recovery based on its performance under the contracts with, and actions taken by, MHI. DBT is continuing to evaluate the claims and the amounts owed to it under the contracts based on MHI’s failure to comply with its contractual obligations. The amounts DBT may recover for current and potential future claims against MHI are not currently known given (i) the extent of current and potential future claims by MHI against DBT (see below for further discussion) and (ii) the unpredictable nature of any dispute resolution processes that may occur in connection with these current and potential future claims. No revenue has been recorded in the accompanying condensed consolidated financial statements with respect to current or potential future claims against MHI. On July 23, 2020, a dispute adjudication panel issued a ruling in favor of DBT on certain matters related to the Kusile and Medupi projects. The panel (i) ruled that DBT had achieved takeover on 9 of the units; (ii) ordered MHI to return $2.3 of bonds (which have been subsequently returned by MHI); (iii) ruled that DBT is entitled to the return of an additional $4.3 of bonds upon the completion of certain administrative milestones; (iv) ordered MHI to pay South African Rand 18.4 (or $1.1 at the time of the ruling) in incentive payments for work performed by DBT (which MHI has subsequently paid); and (v) ruled that MHI waived its rights to assert delay damages against DBT on one of the units of the Kusile project. The ruling is subject to MHI’s rights to seek further arbitration in the matter, as provided in the contracts. As such, the incentive payments noted above have not been recorded in our accompanying condensed consolidated statements of operations. On February 22, 2021, a dispute adjudication panel issued a ruling in favor of DBT related to costs incurred in connection with delays on two units of the Kusile project. In connection with the ruling, MHI paid DBT South African Rand 126.6 (or $8.6 at the time of payment). This ruling was subject to final and binding arbitration in this matter. In March 2023, an arbitrator upheld the decision of the dispute adjudication panel. As a result, the South African Rand 126.6 (or $7.0) was recorded as income during the quarter ended April 1, 2023, with such amount recorded within “Gain (loss) on disposition of discontinued operations, net of tax.” On April 28, 2021, a dispute adjudication panel issued a ruling in favor of DBT related to costs incurred in connection with delays on two units of the Medupi project. In connection with the ruling, MHI paid DBT South African Rand 82.0 (or $6.0 at the time of payment). This ruling is subject to MHI’s rights to seek further arbitration in the matter and, thus, the amount awarded has not been reflected in our accompanying condensed consolidated statements of operations. Claims by MHI - On February 26, 2019, DBT received notification of an interim claim consisting of both direct and consequential damages from MHI alleging, among other things, that DBT (i) provided defective product and (ii) failed to meet certain project milestones. In September 2020, MHI made a demand on certain bonds issued in its favor by DBT, based solely on these alleged defects, but without further substantiation or other justification (see further discussion below). On December 30, 2020, MHI notified DBT of its intent to take these claims to binding arbitration even though the vast majority of these claims had not been brought appropriately before a dispute adjudication board as required under the relevant subcontracts. On June 4, 2021, in connection with the arbitration, DBT received a revised version of the claim. Similar to the interim claim, we believe the vast majority of the damages summarized in the revised claim are unsubstantiated and, thus, any loss for the majority of these claims is considered remote. The remainder of the claims in both the interim notification and the revised version largely appear to be direct in nature. On September 21, 2022, an arbitration tribunal ruled that only South African Rand 349.6 (or $19.3 ) of MHI’s revised claim had been brought appropriately before a dispute adjudication board as required under the relevant subcontracts, with MHI’s other claims dismissed from the arbitration proceedings. MHI subsequently referred the claims dismissed from the arbitration, with approximately South African Rand 400.2 (or $22.1) related to claims that are direct in nature, to a new dispute adjudication panel. DBT has numerous defenses and, thus, we do not believe that DBT has a probable loss associated with any of these claims. As such, no loss has been recorded in the accompanying condensed consolidated financial statements with respect to these claims. DBT intends to vigorously defend itself against these claims. Although it is reasonably possible that some loss may be incurred in connection with these claims, we currently are unable to estimate the potential loss or range of potential loss associated with these claims due to the (i) lack of support provided by MHI for these claims; (ii) complexity of contractual relationships between the end customer, MHI, and DBT; (iii) legal interpretation of the contract provisions and application of South African law to the contracts; and (iv) unpredictable nature of any dispute resolution processes that may occur in connection with these claims. In April and July 2019, DBT received notifications of intent to claim liquidated damages totaling South African Rand 407.2 (or $22.5 ) from MHI alleging that DBT failed to meet certain project milestones related to the construction of the filters for both the Kusile and Medupi projects. DBT has numerous defenses against these claims and, thus, we do not believe that DBT has a probable loss associated with these claims. As such, no loss has been recorded in the accompanying condensed consolidated financial statements with respect to these claims. Although it is reasonably possible that some loss may be incurred in connection with these claims, we currently are unable to estimate the potential loss or range of potential loss. In March 2023, MHI submitted to DBT notices of intent to claim totaling South African Rand 1,664.0 (or $92.0) related to DBT’s filter and heater scopes of work, alleging that DBT provided defective product. MHI has provided minimal support for these allegations and DBT believes it has numerous defenses against them. Thus, we do not believe that DBT has a probable loss associated with these allegations and DBT intends to vigorously defend itself against them. As such, no amounts have been recorded in the accompanying condensed consolidated financial statements with respect to these allegations. We currently are unable to estimate the range of potential loss, if any, associated with these allegations due to the (i) lack of support provided by MHI; (ii) complexity of contractual relationships between the end customer, MHI, and DBT; (iii) legal interpretation of the contract provisions and application of South African law to the contracts; and (iv) unpredictable nature of any dispute resolution processes that may occur in connection with these claims. Bonds Issued in Favor of MHI - DBT was obligated with respect to bonds issued by banks in favor of MHI. In September of 2020, MHI made a demand, and received payment of South African Rand 239.6 (or $14.3 at the time of payment), on certain of these bonds. In May 2021, MHI made an additional demand, and received payment of South African Rand 178.7 (or $12.5 at the time of payment), on certain of the remaining bonds at such time. In both cases, we funded the payment as required under the terms of the bonds and our senior credit agreement. In its demands, MHI purported that DBT failed to carry out its obligations to rectify certain alleged product defects and that DBT failed to meet certain project milestones. DBT denies liability for such allegations and, thus, fully intends to seek, and believes it is legally entitled to, reimbursement of the South African Rand 418.3 (or $23.1 ) that has been paid. On October 11, 2022, a dispute adjudication panel ruled MHI drew on amounts in excess of the bond values stipulated in the contracts and was required to refund DBT South African Rand 90.8 (or $5.0 at the time of payment) of the previously demanded amounts, plus interest of South African Rand 12.5 (or $0.7 at the time of payment). MHI paid these amounts on October 14, 2022. We have reflected the remaining South African Rand 327.5 (or $18.1 and $19.1 as of April 1, 2023 and December 31, 2022, respectively ) within “Assets of DBT and Heat Transfer” on the accompanying condensed consolidated balance sheets as of April 1, 2023 and December 31, 2022. All other bonds previously issued in favor of MHI have been returned or cancelled by the issuing banks. In addition, SPX Technologies, Inc. has guaranteed DBT’s performance on these projects to the prime contractors, including MHI. Claim against Surety - On February 5, 2021, DBT received payment of $6.7 on bonds issued in support of performance by one of DBT’s sub-contractors. The sub-contractor maintains a right to seek recovery of such amount and, thus, the amount received by DBT has not been reflected in our condensed consolidated statements of operations. Claim for Contingent Consideration Related to ULC Robotics (“ULC”) Acquisition In connection with our acquisition of ULC in September 2020, the seller of ULC was eligible for additional cash consideration of up to $45.0 upon achievement of certain operating and financial performance milestones. During the third quarter of 2021, we concluded that the operational and financial performance milestones noted above were not achieved and, thus, no amount is due to the seller. On August 23, 2022, the seller of ULC initiated a breach-of-contract lawsuit against us in the United States District Court for the Eastern District of New York claiming that it is entitled to a portion of the additional cash consideration linked to certain operating performance milestones totaling $15.0. SPX has numerous defenses against this claim and, thus, we do not believe we have a probable loss associated with the claim. Litigation Matters We are subject to other legal matters that arise in the normal course of business. We believe these matters are either without merit or of a kind that should not have a material effect, individually or in the aggregate, on our financial position, results of operations or cash flows; however, we cannot assure you that these proceedings or claims will not have a material effect on our financial position, results of operations or cash flows. Environmental Matters Our operations and properties are subject to federal, state, local and foreign regulatory requirements relating to environmental protection. It is our policy to comply fully with all applicable requirements. As part of our effort to comply, we have a comprehensive environmental compliance program that includes environmental audits conducted by internal and external independent professionals, as well as regular communications with our operating units regarding environmental compliance requirements and anticipated regulations. Based on current information, we believe that our operations are in substantial compliance with applicable environmental laws and regulations, and we are not aware of any violations that could have a material effect, individually or in the aggregate, on our business, financial condition, and results of operations or cash flows. We had liabilities for site investigation and/or remediation at 17 sites that we own or control, as of April 1, 2023 and December 31, 2022. In addition, while we believe that we maintain adequate accruals to cover the costs of site investigation and/or remediation, we cannot provide assurance that new matters, developments, laws and regulations, or stricter interpretations of existing laws and regulations will not materially affect our business or operations in the future. Our environmental accruals cover anticipated costs, including investigation, remediation, and maintenance of clean-up sites. Our estimates are based primarily on investigations and remediation plans established by independent consultants, regulatory agencies and potentially responsible third parties. Accordingly, our estimates may change based on future developments, including new or changes in existing environmental laws or policies, differences in costs required to complete anticipated actions from estimates provided, future findings of investigation or remediation actions, or alteration to the expected remediation plans. It is our policy to revise an estimate once it becomes probable and the amount of change can be reasonably estimated. We generally do not discount our environmental accruals and do not reduce them by anticipated insurance recoveries. We take into account third-party indemnification from financially viable parties in determining our accruals where there is no dispute regarding the right to indemnification. In the case of contamination at offsite, third-party disposal sites, as of April 1, 2023 and December 31, 2022 , we have been notified that we are potentially responsible and have received other notices of potential liability pursuant to various environmental laws at 9 sites, at which the liability has not been settled, and all of which have been active in the past few years. These laws may impose liability on certain persons that are considered jointly and severally liable for the costs of investigation and remediation of hazardous substances present at these sites, regardless of fault or legality of the original disposal. These persons include the present or former owners or operators of the site and companies that generated, disposed of or arranged for the disposal of hazardous substances at the site. We are considered a “de minimis” potentially responsible party at most of the sites, and we estimate that our aggregate liability, if any, related to these sites is not material to our condensed consolidated financial statements. We conduct extensive environmental due diligence with respect to potential acquisitions, including environmental site assessments and such further testing as we may deem warranted. If an environmental matter is identified, we estimate the cost and either establish a liability, purchase insurance or obtain an indemnity from a financially sound seller; however, in connection with our acquisitions or dispositions, we may assume or retain significant environmental liabilities, some of which we may be unaware. The potential costs related to these environmental matters and the possible impact on future operations are uncertain due in part to the complexity of government laws and regulations and their interpretations, the varying costs and effectiveness of various clean-up technologies, the uncertain level of insurance or other types of recovery, and the questionable level of our responsibility. We record a liability when it is both probable and the amount can be reasonably estimated. In our opinion, after considering accruals established for such purposes, the cost of remedial actions for compliance with the present laws and regulations governing the protection of the environment are not expected to have a material impact, individually or in the aggregate, on our financial position, results of operations or cash flows. Self-Insured Risk Management Matters We are self-insured for certain of our workers’ compensation, automobile, product and general liability, disability and health costs, and we believe that we maintain adequate accruals to cover our retained liability. Our accruals for risk management matters are determined by us, are based on claims filed and estimates of claims incurred but not yet reported, and generally are not discounted. We consider a number of factors, including third-party actuarial valuations, when making these determinations. We maintain third-party stop-loss insurance policies to cover certain liability costs in excess of predetermined retained amounts. This insurance may be insufficient or unavailable (e.g., because of insurer insolvency) to protect us against loss exposures. |
